國際土木工程合同（14份范本）

第1篇 國際土木工程招投標（邀請書）

日期：_________年_________月_________日（發(fā)出邀請時間）

貸款編號：_________

合同編號：_________

1._________（借方名稱）已經(jīng)從_________銀行收到一筆用于支付_________（工程名稱）費用的以各種貨幣形式體現(xiàn)的貸款，該貸款收入的一部分將用于支付_________工程合同項目下的合格費用。

2._________（業(yè)主名稱）現(xiàn)從_________成員國中邀請有預選資格的合格投標者進行密封投標，為實施及完成工程提供所需要的勞務、材料、設備及服務。

3.投標者可從標書上獲得進一步的信息，可從（_________）辦公室查閱投標文件和資料。_________（買方單位名稱、發(fā)放投標資料及資料辦公室的郵政地址、電傳電報號）。

4.有興趣的合格投標者可向上述地址提出書面申請并交付一筆不可退用的金額，即可購買一整套投標文件資料。

5.所有的投標者都需繳納總投標價的2％或一定金額的保證金，并按投標需知于開標前交清，然后立即公開開標。

6._________（業(yè)主）不負擔投標人因準備或提交投標所發(fā)生的任何開支或費用，包括與參觀現(xiàn)場有關的開支或費用。

7.不考慮可選擇標（可提交與規(guī)范說明中的規(guī)范不一致但卻滿足要求的或達到規(guī)范的可選擇標。但只有主標為最低評估標時，可選擇標才會被考慮?？蛇x擇標需與主標分開，密封并標明“可選擇標”。）

第2篇 國際土木工程招投標（邀請書）新

日期：_________年_________月_________日（發(fā)出邀請時間）

貸款編號：_________

合同編號：_________

1．_________（借方名稱）已經(jīng)從_________銀行收到一筆用于支付_________（工程名稱）費用的以各種貨幣形式體現(xiàn)的貸款，該貸款收入的一部分將用于支付_________ 工程合同 項目下的合格費用。

2．_________（業(yè)主名稱）現(xiàn)從_________成員國中邀請有預選資格的合格 投標 者進行密封投標，為實施及完成工程提供所需要的勞務、材料、設備及服務。

3．投標者可從標書上獲得進一步的信息，可從（_________）辦公室查閱投標文件和資料。_________（買方單位名稱、發(fā)放投標資料及資料辦公室的郵政地址、電傳電報號）。

4．有興趣的合格投標者可向上述地址提出書面申請并交付一筆不可退用的金額，即可購買一整套投標文件資料。

5．所有的投標者都需繳納總投標價的2％或一 定金 額的 保證金 ，并按投標需知于開標前交清，然后立即公開開標。

6．_________（業(yè)主）不負擔投標人因準備或提交投標所發(fā)生的任何開支或費用，包括與參觀現(xiàn)場有關的開支或費用。

7．不考慮可選擇標（可提交與規(guī)范說明中的規(guī)范不一致但卻滿足要求的或達到規(guī)范的可選擇標。但只有主標為最低評估標時，可選擇標才會被考慮。可選擇標需與主標分開，密封并標明“可選擇標”。）

第3篇 國際土木工程建筑承包合同（中英文對照）

part工general conditions

第一章 總則

definitions and interpretation

定義和釋義

1．（1）in the contract，as hereinafter defined，the following words and expressions shall have the meanings hereby assigned to them，except where the context otherwise requires：

1．1在本合同中，除按上下文另具意義者外，下列詞語應解釋如下：

（a）'employer' means the party named in part ii who will employ the contractor and the legal successors in title to the employer，but not，except with the consent of the contractor，any assignee of the employer．

“業(yè)主”指第二章中所指定的雇用承包人的一方或其權利 繼承人 ，但不包括業(yè)主的受讓人，經(jīng)承包人同意者除外。

（b）“contractor”means the person or persons，firm or company whose tender has been accepted by the employerand includes the contractor’s personal representatives，successors and permitted assigns．

“承包人”指標書已被業(yè)主接受的某個或某些人、商行或公司，包括其個人代表，繼承人和業(yè)經(jīng)認可的受讓人。

（c）“engineer”means the engineer designated as such in part ii，or other engineer appointed from time to time by the employer and notified in writing to the contractor to act as engineer for the purposes of the contract in place of the engineer、designated．

“工程師”指第二章中所指定的工程師，或由業(yè)主隨時任命且書面通知承包人以代替指定工程師履行合同職責的其他工程師。

（d) 'engineer’s representative' means any resident engineer or assistant of the engineer or any clerk of works appointed from time to time by the employer or the engineer to perform the duties set forth in clause 2 hereof，whose authority shall be notified in writing to the contractor by the engineer．

“工程師代表”指任何常駐工程技術人員、工程師助手，或由業(yè)主或工程師隨時任命履行本合同第二條規(guī)定職責的任何工程現(xiàn)場監(jiān)督，其權限應由工程師書面通告承包人。

（e) “works” shall include both permanent works and temporary works，

“工程”包括永久性工程和臨建工程。

（f）“contract” means the conditions of contract，specification，drawings，priced bill of quantities，schedule of rates and prices，if any，tender，letter of acceptance and the contract agreement，if completed．

“合同”指合同條款、技術規(guī)范、圖紙、標價的建筑工程清單、單價和價格表（如果有），還可指標書、接受證書以及承包協(xié)議（如已完成）。

（g) “contract price” means the sum named in the letter of acceptance, subject to such additions thereto or deductions therefrom as may be made under the provisions hereinafter contained．

“合同價格”指在接受證書中確定的數(shù)額，可按本合同以下條款規(guī)定增減。

（h)“constructional plant' means all appliances or things of whatsoever nature required in or about the execution or maintenance of the works but does not include materials or other things intended to form or forming part of the permanent works．

“建筑設備”指工程施工和維修中或有關施工和維修所需的全部設備或物品，不論任何性質，但不包括旨在構成或正在構成永久性工程某一部分的材料或其他物品。

（i）“temporary works' means all temporary works of every kind required in or about the execution or maintenance of the works．

“臨建工程”指工程施工或維修或有關工程施工或維修所需的各種 臨時工 程。

（j）“permanent works”means the permanent works to be executed and maintained in accordance with the contract．

“永久性工程”指按合同將施工和維修的永久工程。

（k） “specification” means the specification referred to in the tender and any modification thereof or addition thereto as may from time to time be furnished or approved in writing by the engineer．

“技術規(guī)范”指在標書或任何標書更改中提及的規(guī)范，或由工程師隨時可能增加或書面同意增加的部分。

（1）“drawings” means the drawings referred to in the specification and any modification of such drawings approved in writing by the engineer and such other drawings as may from time to time be furnished or approved in writing by the engineer．

“圖紙”指技術規(guī)范中規(guī)定的圖紙，經(jīng)工程師書面同意對此種圖紙所作的任何更改，以及可由工程師隨時提供或書面認同的其他圖紙。

（m） “site” means the land and other places on，under，in or through which the permanent works or temporary works designed by the engineer are to be executed and any other lands and places provided by the employer for working space or any other purpose as may be apecifically designated in the contract as forming part of the site．

“工地”指工程師設計的永久性或臨建工程施工所需的土地及其他場地，包括地面、地下、在之上或通過部分，以及由業(yè)主所提供的用作臨時儲存或其他目的的其他土地或場所，只要能按合同明文規(guī)定構成工地的組成部分。

（n）“approved” means approved in writing，including subsequent written confirmation ofprevious verbalapproval and“approval' means approval in writing，including as aforesaid．

“業(yè)經(jīng)認可”指已經(jīng)經(jīng)書面認可，包括過后對口頭認可的書面確認，“認可”指書面認可，包括上述規(guī)定在內(nèi)。

（2）words importing the singular only also include the plural and vice versa where the context requires·

1．2按合同上下文所需，單數(shù)含義的單詞也可具有復數(shù)的含義，反之一樣。

（3）the headings and marginal notes in these conditions of contract shall not be deemed to be part thereof or be taken into consideration in the interpretation or construction thereof or of the contract．

1．3合同條款的標題和邊注不得視為合同的一部分，不得用于考慮解釋條款或合同。

（4）the word“cost' shall be deemed to include overhead costs whether on or off the site．

1．4“費用”一詞應視為含工地上或以外發(fā)生的間接費用。

engineer and engineer’s reprf．sfntative

工程師及工程師代表

2．（1）the engineer shall carry out such duties in issuing decisions，certificates and orders as are specified in the contract．in the event of the engineer being required in terms of his appointment by the employer to obtain the specific approval of the employer for the execution of any part of these duties，this shall be set out in part ii of these conditions．

2．1工程師必須按合同明文規(guī)定，履行作決斷、頒發(fā)證書和發(fā)出指令等職責。如業(yè)主簽發(fā)的工程師任命書中規(guī)定其某些職責的履行得經(jīng)業(yè)主專門認可，其要件應在本合同第二部分予以規(guī)定。

（2）the engineer may from time to time in writing delegate to the engineer's representative any of the powers and authorities vested in the engineer and shall furnish to the contractor and to the employer a copy of all such written delegations of powers and authorities． any written instruction or approval given by the engineer’s representative to the contractor within the terms of such delegation，but not otherwise，shall bind the contractor and the employer as though it had been given by the engineer．provided always as follws：

2．2工程師可隨時書面授權其代表代行其任何職權，但必須將所有此種授權書的副本提交給承包人和業(yè)主。在授權期間，工程師代表給承包人的任何書面指令或認可（僅限于此）對承包人和業(yè)主具有與工程師的指令或認可同樣的效力。以下規(guī)定屬于例外：

（a） failure of the engineer's representative to disapprove any work or materials shall not prejudice the power of the engineer thereafter to disapprove such work or materials and to order the pulling down，removal or breaking up thereof．

工程師代表對任何工程或材料的不予否認，不得影響工程師此后否認以及命令拆毀、移動或拆除此種工程或材料的權力。

（b）if the contractor shall be dissatisfied by reason of any decisions of the engineer's representative he shall be entitled to refer the matter to the engineer，who shall thereupon confirm，reverse or vary such decision．

若承包人對工程師代表的任何決定不滿意，其有權將此決定提交工程師確認、取消或更改。

assignment and sub—letting

轉讓和分包

3．the contractor shall not assign the contract or any part thereof，or any benefit or interest therein or thereunder，otherwise than by a charge in favor of the contractor's bankers of any monies due or to become due under this contract，without the prior written consent of the employer．

3．未經(jīng)業(yè)主事前書面同意，承包人不得將合同或其他任何部分，或合同所規(guī)定或依合同而產(chǎn)生的任何收益轉讓，向承包人的開戶銀行支付按本合同規(guī)定到期或即將到期的款項除外。

4．the contractor shall not sub-let the whole of the works．except where otherwise provided by the contract，the contractor shall not sub-let any part of the works without the prior written consent of the engineer，which shall not be unreasonably withheld，and such consent，if given，shall not relieve the（contractor from any liability or obligation under the contract and he shall be responsible for the acts，defaults and neglects of any sub-contractor，his agents，servants or workmen as fully as if they were the acts，defaults or neglects of the contractor，his agents． servants or workmen．provided always that the provision of labor on a piecework basis shall not be deemed to be a subletting under the clause．

4．承包人不得轉包整個工程。除非合同另有規(guī)定，未經(jīng)工程師事前書面同意，承包人也不得分包工程的任何部分，但工程師不得無故不同意分包，一旦同意分包，此種同意不得免去承包人所承擔的任何合同所規(guī)定的責任或義務，他必須對任何分包人、其 代理 人、雇員或工人的行為、不履行和過失負完全責任，如同這些行為、不履行或過失是承包人、其代理人、雇員或工人所為。以計件方式提供勞力不得視為是本條所規(guī)定的分包。

contract documents

合同文件

5．（1）there shall be stated in part 1i of these conditions：

5．1以下要件得在合同第二部分規(guī)定：

（a）the language or languages in which the contract documents shall be drawn up and．

用以起草合同文件的語言；

（b）the country or state，the law of which is to apply to the contract and according to which

the contract is to be construed．

合同適用哪個國家的法律以及用哪個國家的法律解釋合同。

if the said documents are written in more than one language，the language according to which the contract is to be construed and interpreted shall also be designated in part ii，being therein designated the “ruling language”．

如果文件用一種以上語言作成，用以解釋合同的語言也必須在第二部分中規(guī)定，且將被寇為“主體語言”。

（2）except if and to the extent otherwise provided by the contract，the provisions of the conditions of contract parts ⅰ and ⅱshall prevail over those of any other document forming part of the contract．subject to the foregoing，the several documents forming the contract are to be taken as mutually explanatory of one another，but in case of ambiguities or discrepancies the same shall be explained and adjusted by the engineer who shall thereupon issue to the contractor instructions thereon．provided always that if，in the opinion of the engineer，compliance with any such instructions shall involve the contractor in any cost，which by reason of any such ambiguity or discrepancy could not reasonably have been foreseen by the contractor，the engineer shall certify and the employer shall pay such additional sum as may be reasonable to cover such costs．

5．2除合同中另有規(guī)定外，合同第一、二部分的條款規(guī)定優(yōu)于其他任何構成合同的文件的規(guī)定。以上述規(guī)定為準，構成合同的數(shù)個文件可視為能互相解釋，如意思含糊或不一致時，由工程師解釋和處理，并由此向承包人發(fā)出指令。如工程師認為，服從此種指令會使承包人發(fā)生額外費用，而此種費用是承包人由于上述意思含糊或不一致而按理無法預見的，工程師應予以證明，業(yè)主必須支付相應的額外款額以補償此種費用。

6．（1）the drawings shall remain in the sole custody of the engineer，but two copies thereof shall be furnished to the contractor free of charge．the contractor shall provide and make at his own expense any further copies required by him．a(chǎn)t the completion of the contract the contractor shall return to the engineer all drawings provided under the contract．

6．1圖紙由工程師獨自保管，但須向承包人免費提供兩份副本。承包人所需的其余副本由他自己制作并承擔費用。 合同履行 后，承包人須將全部合同圖紙歸還工程師。

（2）one copy of the drawings，furnished to the contractor as aforesaid，shall be kept by the contractor on the site and the same shall at all reasonable times be available for inspection and use by the engineer and the engineer's representative and by any other person authorized by the engineer in writing．

6．2承包人必須將按上述規(guī)定所提交的一份圖紙副本留在工地，讓工程師及其代表，或工程師書面授權的任何其他人在所有合理的時間內(nèi)查閱使用。

（3）the contractor shall give written notice to the engineer whenever planning or progress of the works' is likely to be delayed or disrupted unless any further drawing or order，including a direction，instruction or approval，is issued by the engineer within a reasonable time．the notice shall include details of the drawing or order required and of why and by when it is required and of any delay or disruption likely to be suffered if it is late．

6．3如工程師不在適當時間內(nèi)再提供圖紙或命令，包括指示、指令或認可，工程計劃或進展便可能被延誤或中斷時，承包人必須書面通知工程師。通知書中應詳細說明所需的圖紙或命令，所需原因和時間，以及如果不及時提供而可能造成的任何延誤和中斷。

（4）if，by reason of any failure or inability of the engineer to issue within a time reasonable in all the circumstances any drawing or order requested by the contractor in accordance with subclause（3）of this clause，the contractor suffers delay and/or incurs costs then the engineer shall take such delay into account in determining any extension of time to which the contractor is entitled under clause 44 hereof and the contractor shall be paid the amount of such cost as shall be reasonable．

6．4如承包人按本條第3款規(guī)定索要圖紙或命令，由于工程師沒有或不能在合理時間內(nèi)

提供，從而導致承包人誤工和左戊承擔費用，工程師必須考慮此種延誤，以決定是否按本合同第44條規(guī)定延長承包人的工期，且只要有理由，承包人所承擔的此種費用必須得到補償。

7．the engineer shall have full power and authority to supply to the contractor from time to time, during the progress of the works，such further drawings and instructions as shall be necessary for the purpose of the proper and adequate execution and maintenance of the works． the contractor shall carry out and be bound by the same．

7．在施工期間，工程師全權負責隨時進一步向承包人提供圖紙和指示，以滿足工程正常施工和維護所需。承包人必須執(zhí)行且受圖紙和指示的約束。

general obligations

總義務

8．（1）the contractor shall，subject to the provisions of the contract，and with due care and diligence, execute and maintain the works and provide all labor，including the supervision thereof, materials，constructional plant and all other things，whether of a temporary or permanent nature，required in and for such execution and maintenance，so far as the necessity for providing the same is specified in or is reasonably to be inferred from the contract．

8．1承包人必須根據(jù)合同條款，對工程的施工和維護予以應有的注意，且提供此種施工和維護所必需的包括勞動管理在內(nèi)的所有勞力、材料、施工成套設備及其他一切物品，不管其是臨時或長期性質，只要合同明文規(guī)定需要或根據(jù)合同合理推斷需要。

（2）the contractor shall take full responsibility for the adequacy，stability and safety of all site operations and methods of construction，provided that the contractor shall not be responsible, except as may be expressly provided in the contract，for the design or specification of the permanent works，or for the design or specification of any temporary works prepared by the engineer·

8．2承包人必須對現(xiàn)場操作和施工方法的恰當、穩(wěn)定及安全性負全部責任。除非合同另有明文規(guī)定，承包人對工程師制定的永久性工程的設計或規(guī)格，或臨建工程的設計或規(guī)格概不負責。

9．the contractor shall，when called upon so to do，enter into and execute a contract agreement，to be prepared and completed at the cost of the employer，in the form annexed with such modification as may be necessary，

9．如經(jīng)要求，承包人必須簽署一承包協(xié)議，該協(xié)議由業(yè)主制定并承擔費用，協(xié)議應附帶必要的修正條款。

10．if，for the due performance of the contract，the tender shall contain an undertaking by

the contractor to obtain，when required，a bond or guarantee of an insurance company or bank, or other approved sureties to be jointly and severally bound with the contractor to the employer, in a sum not exceeding that stated in the letter of acceptance for such bond or guarantee，the said insurance company or bank or sureties and the terms of the said bond or guarantee shall be such as shall be approved by the employer． the obtaining of such bond or guarantee or theprovision of such sureties and the cost of the bond or guarantee to be so entered into shall be at the expense in all respects of the contractor，unless the contract otherwise provides．

10．為正常履行合同，在標書中，承包人應承諾按要求取得保險公司或銀行的保單或保函，或其他業(yè)經(jīng)認可由承包人向業(yè)主負 連帶責任 的擔保，其數(shù)額不超過驗收證書中規(guī)定的保單或保函額，上述保險公司、銀行或擔保以及上述保單或保函的條款必須經(jīng)業(yè)主認可。此種保單或保函的取得或擔保的提供，以及締結保單或保函的費用應全部由承包人承擔，合同中另有規(guī)定的除外。

11．the employer shall have made available to the contractor with the tender documents such data on hydrological and sub-surface conditions as shall have been obtained by or on behalf of the employer from investigations undertaken relevant to the works and the tender shall be deemed to have been based on such data，but the contractor shall be responsible for his own interpretation thereof．

11．業(yè)主必須在 招標 文件中向承包人提供由業(yè)主或其代理人在進行工程考察時獲得的水文及地質情況資料，標書必須視為是基于此種資料所制定的，但承包人必須對資料的理解自行負責。

the contractor shall also be deemed to have inspected and examined the site and its surroundings and information available in connection therewith and to have satisfied himself，so far as is practicable，before submitting his tender，as to the form and nature thereof，including the sub-surface conditions，the hydrological and climatic conditions，the extent and nature of work and materials necessary for the completion of the works，the means of access to the site and the accommodation he may require and，in general，shall be deemed to have obtained all necessary information，subject as above mentioned，as to risks，contingencies and all other circumstances which may influence of affect his tender．

承包人也必須被視為已視察了工地及周圍環(huán)境，查閱了可獲得的有關工地資料，且在提交標書前，對一切實際情況，從形式到性質，包括地質條件、水文和氣候條件、工程范圍和性質以及完成工程所必需的材料、到達工地的交通工具和所需的食宿等感到滿意，總之，承包人必須被視為已得到所有必要的資料，除涉及上述情況外，還涉及風險、意外事件及其他一切可能影響其 投標 的情況。

12．the contractor shall be deemed to have satisfied himself before tendering as to the correctness and sufficiency of his tender for the works and of the rates and prices stated in the priced bill of quantities and the schedule of rates and prices，if any，which tender rates and prices shall，except insofar as it is otherwise provided in the contract，cover all his obligations under the contract and all matters and things necessary for the proper execution and maintenance of the works．if，however，during the execution of the works the contractor shall encounter physical conditions，other than climatic conditions on the site，or artificial obstructions，which conditions or obstructions could，in his opinion，not have been reasonably foreseen by an experienced contractor，the contractor shall forthwith give written notice thereof to the engineer's representative and if，in the opinion of the engineer，such conditions or artificial obstructions could not have been reasonably foreseen by an experienced contractor，then the engineer shall certify and the employer shall pay the additional cost to which the contractor shallhave been put by reason of such conditions，including the proper and reasonable cost．

12．承包人得被視為在投標前已對其工程標書，對標價的建筑工程清單、單價和價格表（如果有）上所列的單價和價格的正確性和完善性感到滿意，此種投標價格必須貫穿其所有的合同義務，適用于所有為工程的正常施工和維護所必需的事物，除非本合同另有規(guī)定。然而，在施工期間，如承包人遇到除工地氣候之外的其他自然情況或人為阻礙，依他所見，此種自然情況或人為阻礙是經(jīng)驗豐富的承包人也無法預見的，承包人必須立即書面通知工程師代表，如工程師確認此種情況或人為阻礙為經(jīng)驗豐富的承包人無法合理預見，工程師必須作證且業(yè)主支付承包人由于此種情況而承擔的額外費用，包括因遇到此種情況或阻礙而：

（a）of complying with any instruction which the engineer may issue to the contractor in connection therewith，and

（1）為執(zhí)行工程師可能向承包人發(fā)出的與此情況有關的任何指示而發(fā)生的正當合理的費用，以及

（b）of any proper and reasonable measures approved by the engineer which the contractor may take in the absence of specific instructions from the engineer．a(chǎn)s a result of such conditions or obstructions being encountered．

（2）在無工程師具體指示時，承包人可能采取業(yè)經(jīng)工程師認可的恰當和合理措施而發(fā)生的正當合理費用。

13．save insofar as it is legally or physically impossible，the contractor shall execute and maintain the works in strict accordance with the contract to the satisfaction of the engineer and shall comply with and adhere strictly to the engineer's instructions and directions on any matter whether mentioned in the contract or not，touching or concerning the works．the contractor shall take instructions and directions only from the engineer or，subject to the limitations referred to in clause 2 hereof，from the engineer's representative．

13．除因法律或自然因素而不能之外，承包人必須嚴格按合同規(guī)定施工和維護工程，使工程師感到滿意，且必須遵守和嚴格執(zhí)行工程師有關任何事項的指令和指示，不管合同中是否有規(guī)定，提及或涉及到工程，承包人只能從工程師處接受指令和指示，或根據(jù)本合同第2條規(guī)定，接受工程師代表的指令和指示。

14．（1）within the time stated in part 11 of these conditions，the contractor shall，after the acceptance of his tender，submit to the engineer for his approval a program showing the order of procedure in which he proposes to carry out the works．the contractor shall，whenever required by the engineer or engineers’representative，also provide in writing for his information a general description of the arrangements and methods which the contractor proposes to adopt for the execution of the works．

14．1中標后，承包人得在第二部分條款規(guī)定的時間內(nèi)向工程師提交一份其計劃施工的程序方案，以征得工程師的認可。承包人還得隨時應工程師或其代表的要求，提供一份承包人的施工計劃安排和方法的說明書，以供其參考。

（2）if at any time it should appear to the engineer that the actual progress of the works does not conform to the approved program referred to in sub-clause（1）of this clause，the contractorshall produce，at the request of the engineer，a revised program showing the modifications to the approved program necessary to ensure completion of the works within the time for completion asdefined in clause 48 hereof．

14．2不論何時，只要工程師發(fā)現(xiàn)工程實際進度與本條第1款規(guī)定的業(yè)經(jīng)認可的方案不符，承包人必須應工程師的要求，提供一份修改方案，對原有的方案作必要的修正，以保證工程能在本合同第48條規(guī)定的期限內(nèi)完工。

（3）the submission to and approval by the engineer or engineer's representative of such programs of the furnishing of such particulars shall not relieve the contractor of any of his duties or responsibilities under the contract．

14．3承包人不得因向工程師或工程師代表提交或經(jīng)其認可此種方案或因提供此種細節(jié)，而被免除任何合同責任或義務。

15．the contractor shall give or provide all necessary super- intendance during the execution of the works and as long thereafter as the engineer may consider necessary for the proper fulfilling of the contractor's obligations under the contract．the contractor，or a competent and authorized agent or representative approved of in writing by the engineer，which approval may at any time be withdrawn，is to be constantly on the works and shall give his whole time to the super-intendance of the same．if such approval shall be withdrawn by the engineer，the contractor shall，as soon as is practicable，having regard to the requirement of replacing him as hereinafter mentioned，after receiving written noticeof suchwithdrawal，remove the agent from the works and shall not thereafter employ him again on the works in any capacity and shall replace him by another agent approved by the engineer．such authorized agent or representative shall receive，on behalf ofthe contractor，directions and instructions from the engineer or， subject to the limitations of clause 2 hereof，the engineer's representative．

15．在施工期間，以及其后在工程師認為是為正常履行合同義務而必需時，承包人必須行使一切監(jiān)督權。承包人，或其經(jīng)工程師書面認可的全權代理人或代表（此種認可可隨時撤銷）應當隨時在工地，一直進行監(jiān)督管理。如工程師撤銷對代理人的認可，在接到書面撤銷通知后，承包人必須盡快根據(jù)撤換規(guī)定，將其撤離工地，且今后不得再在工地上以任何身份雇傭他（她），且用另外一位經(jīng)工程師認可的代理人予以替代。此種授權代理人或代表得代表承包人接受工程師的指令和指示，或按本合同第2條規(guī)定，接受工程師代表的指令和指示。

16．（1）the contractor shall provide and employ on the site in connection with the execution and maintenance of the works．

16．1承包人必須在工地上提供和雇用與施工和工程維護有關的：

（a） only such technical assistants as are skilled and experienced in their respective callings and such sub-agents，foremen and leading hands as are competent to give proper supervision to the work they are required to supervise，and

（1）對本專業(yè)熟悉和經(jīng)驗豐富的技術人員，能勝任規(guī)定監(jiān)管工作的分代理人、工頭和領班，以及

（b）such skilled，semi-skilled and unskilled labor as is necessary for the proper and timely execution and maintenance of the works．

（2）為正常和及時施工和維護工程所需的熟練、半熟練和非熟練工人。

（2）the engineer shall be at liberty to object to and require the contractor to remove forthwith from the works any person employed by the contractor in or about the execution ormaintenance of the works who，in the opinion of the engineer，misconducts himself，or is incompetent or negligent in the proper performance of his duties，or whose employment is otherwise considered by the engineer to be undesirable and such person shall not be again employed upon the works without the written permission of the engineer．a(chǎn)ny person so removed from the works shall be replaced as soon as possible by a competent substitute approved by the engineer．

16．2如工程師認為承包人雇來進行或有關施工或工程維護的任何人員行為不軌、或不能或疏于履行其職責、或認為其雇傭純屬不必要，工程師有權反對雇傭，并要求承包人立即將其從工地解雇，未經(jīng)工程師的書面同意，此種人員不得再被雇用到工地。凡被從工地解雇人員的職位應盡快由工程師認可的稱職人選接替。

17．the contractor shall be responsible for the true and proper setting-out of the works in relation to original points，lines and levels of reference given by the engineer in writing and for the correctness，subject as above mentioned，of the position，levels，dimensions and alignment of all parts of the works and for the provision of all necessary instruments，appliances and labor in connection therewith．if，at any time during the progress of the works，any error shall appear or arise in the position，levels，dimensions or alignment of any part of the works，the contractor， on being required so to do by the engineer or the engineer's representative，shall，at his own cost，rectify such error to the satisfaction of the engineer or the engineer's representative，unless such error is based on incorrect data supplied in writing by the engineer or the engineer's representative，in which case the expense of rectifying the same shall be borne by the employer． the checking of any setting-out or of any line or level by the engineer or the engineer's representative shall not in any way relieve the contractor of his responsibility for the correctness thereof and the contractor shall carefully protect and preserve all bench-marks， sight-rails，pegs and other things used in setting-out the works．

17．承包人負責按工程師提交的書面參考原圖的有關點、線和面的規(guī)定，忠實恰當?shù)剡M行測定放線，如上所述，使工程的位置、水平、面積正確無誤，并校準工程的各部分，且負責提供與工程相關的所有必要工具、設備和勞力。在施工中，如任何時候在工程的位置、水平、面積或工程任何部分的校正出現(xiàn)差錯，應工程師或工程師代表的要求，承包人必須改正錯誤以使工程師或工程師代表滿意，改正費用由承包人自己承擔，此種錯誤是由工程師或工程師代表提供的書面資料差錯而導致的除外，在這種情況下，須由業(yè)主承擔改正費用。承包人不得因工程師或工程師代表對任何位置測定或任何線或任何水平面的檢查而免去確保其正確無誤的責任，承包人必須仔細保護和保存工程位置測定中使用過的水準點、觀測桿、測標及其他物品。

18．if，at any time during the execution of the works，the engineer shall require the contractor to make bore holes or to carry out exploratory excavation，such requirement shall be ordered in writing and shall be deemed to be an addition ordered under the provisions of clause 51 hereof，unless a provisional sum in respect of such anticipated work shall have been included in the bill of quantities．

18．在施工中，工程師如在任何時間要求承包人鉆孔或進行挖掘勘探，此種要求必須作成書面形式，且得視為是根據(jù)本合同第51條規(guī)定作出的附加命令，除非數(shù)量清單中已經(jīng)列有有關此種預計工程的備用款。

19．the contractor shall in connection with the works provide and maintain at his own cost all lights，guards，fencing and watching when and where necessary or required by the engineer or the engineer's representative，or by any duly constituted authority， for the protection of the works，or for the safety and convenience of the public or others．

19．凡有必要或應工程師或工程師代表、或任何正式成立的工程管理處的要求，承包人必須自費提供和維護與工程有關的所有燈光、警衛(wèi)、柵欄和看護以保衛(wèi)工程，或保障公眾及其他人的安全和便利。

20．（1）from the commencement of the works until the date stated in the certificate of completion for the whole of the works pursuant to clause 48 hereof the contractor shall take full responsibility for the care thereof．provided that if the engineer shall issue a certificate of completion in respect of any part of the permanent works the contractor shall cease to be liable for the care of that part of the permanent works from the date stated in the certificate of completion in respect of that part and the responsibility for the care of that part shall pass to the employer． provided further that the contractor shall take full responsibility for the care of any outstanding work which he shall have undertaken to finish during the period of maintenance until such outstanding work is completed．in case any damage，loss or injury shall happen to the works，or to any part thereof，from any cause whatsoever，save and except the excepted risks as defined in subclause（2）of this clause，while the contractor shall be responsible for the care thereof the contractor shall，at his own cost，repair and make good the same，so that at completion the permanent works shall be in good order and condition and in conformity in every respect with the requirements of the contract and the engineer's instructions．in the event of any such damage loss or injury happening from any of the excepted risks，the contractor shall，if and to the extent required by the engineer and subject always to the provisions of clause 65 hereof， repair and make good the same as aforesaid at the cost of the employer．the contractor shall also be liable for any damage to the works occasioned by him in the course of any operations carried out by him for the purpose of completing any outstanding work or complying with his obligations under clauses 49 or 50 hereof．

20．1從開工至按本合同第48條中的竣工證書規(guī)定的日期為止，承包人都得對工程全權負責。只要工程師就永久性工程的任何部分簽發(fā)了竣工證書，承包人從部分竣工證書中規(guī)定的日期起不再對永久性工程的此部分負責，此部分的責任則轉至業(yè)主。此外，承包人必須對任何尚未完工而他得在維護期內(nèi)完成的工程負全權維護，直至此種工程完工。如工程或其任何部分出現(xiàn)任何損害、損失或毀壞，不論何種原因，除本條第2款規(guī)定的除外風險外，承包人均得自費負責修理和修補，以確保永久性工程竣工時處于狀態(tài)良好，各方面都合乎合同的要求和工程師的指示。如因除外風險而導致任何損害、損失或毀壞發(fā)生，承包人必須應工程師的要求（如果有）以及本合同第65條的規(guī)定，如上所述，進行修理和修補，費用由業(yè)主承擔。承包人也必須對為完成未竣工程或履行本合同第49或50條規(guī)定的義務，在施工過程中對工程造成的任何損害負責。

（2）“the excepted risks' are war，hostilities（whether war be declared or not），invasion act of foreign enemies，rebellion，revolution，insurrection or military or usurped power，civil war，or unless solely restricted to employees of the contractor or of his sub-contractors and arisingfrom the conduct of the works，riot，commotion or disorder，or use or occupation by the employer of any part of the permanent works，or a cause solely due to the engineer's design of the works，or ionizing radiation，or contamination by radio-activity from any nuclear fuel or from any nuclear waste from the combustion of nuclear fuel，radio-active toxic explosive，or other hazardous properties of any explosive，nuclear assembly or nuclear component thereof，pressure waves caused by aircraft or other aerial devices travelling at sonic or supersonic speeds，or any such operation of the forces of nature as an experienced contractor could not foresee，or reasonably -make provision for or insure against all of which are herein collectively referred to as“the excepted risks'．

20．2“除外風險”包括戰(zhàn)爭、敵對狀態(tài)（無論是否宣戰(zhàn)）、侵略、外國敵人行為、叛亂、革命、起義或兵變或篡權、內(nèi)戰(zhàn)、或不是由承包商的雇員、其轉包人單獨制造和不是因工程管理而發(fā)生的暴動、騷亂或混亂、或因業(yè)主使用或占用任何部分的永久性工程、或純屬工程師工程設計的原因、或因任何核燃料或核燃料燃燒后的廢料以及放射性有毒爆炸物引起的輻射和污染、或任何爆炸物、核裝置或核裝置部件的其他危險特性、以音速、超音速飛行的飛機或其他飛行物的壓力波以及其他任何此種自然力的作用，其不能為有經(jīng)驗的承包商所預見，也不能合理提供物資或投保與之對抗，所有這一切在本合同中都被稱為“除外風險”。

21．without limiting his obligations and responsibilities under clause 20 hereof，the contractor shall insure in the joint names of the employer and the contractor against all loss or damage from whatever cause arising，other than the excepted risks，for which he is responsible under the terms of the contract and in such manner that the employer and contractor are covered for the period stipulated in clause 20（1）hereof and are also covered during the period of maintenance for loss or damage arising from a cause，occurring prior to the commencement of the period of maintenance，and for any loss or damage occasioned by the contractor in the course of any operations carried out by him for the purpose of complying with his obligations under clauses 49 and 50 hereof；

21．承包人必須以業(yè)主和承包人的共同名義，為防止合同規(guī)定的應由承包人負責的、除外風險外的一切損失或損害投保，不論其由什么原因造成，此種投保不得減少本合同第20條所規(guī)定的承包人的義務和責任，業(yè)主和承包人的保險除包括本合同第20．1條規(guī)定的期限外，還包括因維護期開始前發(fā)生的原因而在維護期內(nèi)產(chǎn)生的損失或損害，以及承包人在履行本合同第49或50條規(guī)定的義務而開展任何工作期間所造成的任何損失或損害。投保項目包括：

（a）the works for the time being executed to the estimated current contract value thereof，or such additional sum as may be specified in part 11 in the clause numbered 21，together with the materials for incorporation in the works at their replacement value．

（1）正在施工的工程，按其目前的合同價值，或按21條第2款可能規(guī)定的附加款額，連同按替換價值計算的用于工程的材料。

（b）the constructional plant and other things brought on to thethe replacement value of such constructional plant and other things．

（2）承包商帶到工地上的建筑成套設備和其他物品，按其替換價值投保。

such insurance shall be effected with an insurer and in terms apwhich approval shall not be unreasonably withheld, and the contractor shall , whenever required , produce to the engineer or the engineer's representative the policy or policies of insurance and the receipts for payment of the current premiums．

此種保險必須在一保險公司投放，條款得經(jīng)業(yè)主認可，業(yè)主不得無故不同意投保，承包人必須隨時應要求向工程師或工程師代表出示保險單和支付現(xiàn)行保險費的收據(jù)。

22．（1）the contractor shall，except if and so far as the contract provides otherwise，indemnify the employer against all losses and claims in respect of injuries or damage to any person or material or physical damage to any property whatsoever which may arise out of or in consequence of the execution and maintenance of the works and against all claims，proceedings，damages，costs，charges and expenses whatsoever in respect of or in relation thereto except any compensation or damages for or with respect to：

22．1除合同另有規(guī)定外，承包人必須保護業(yè)主不得因施工和工程維護而產(chǎn)生或導致的任何人員傷害、材料損失及財產(chǎn)損失而受任何損失和作任何賠償，且不因所有與之有關的任何索賠、 訴訟 、損害 賠償金 、 訴訟費 、開支和費用而受損失，對下列事項所作或與之有關的補償或損害賠償除外：

（a）the permanent use or occupation of land by the works or any part thereof．

工程或部分工程永久使用或占用土地；

（b）the right of the employer to execute the works or any part thereof on，over，under in or through any land．

業(yè)主在任何土地面上、上方、下面、里面或經(jīng)過部分施工或部分施工的權利；

（c）injuries or damage to persons or property which are the unavoidable result of the execution or maintenance of the works in accordance with the contract．

按合同規(guī)定施工或維護工程而不可避免的人身傷害或財產(chǎn)損失；

（d）injuries or damage to persons or property resulting from any act or neglect of the employer，his agents，servants or other contractors，not being employed by the contractor，or for or in respect of any claims，proceedings，damages，costs，charges and expenses in respect thereof or in relation thereto or where the injury or damage was contributed to by the contractor， his servants or agents such part of the compensation as may be just and equitable having regard to the extent of the responsibility of the employer，his servants or agents or other contractors for the damage or injury．

因業(yè)主、其代理人、雇員或其他不為承包人所雇用的承包商的任何行為或過失所造成的人員傷害或財產(chǎn)損失，或與之有關的任何索賠、訴訟、損害賠償金、訴訟費、開支和費用，或曾由承包人、其雇員或代理人承擔的，但原本應當由業(yè)主、其雇員或代理人或其他承包商負責的那部分涉及損失或傷害的賠償。

（2）the employer shall indemnify the contractor against all claims，proceedings，damages，costs, charges and expenses in respect of the matters referred to in the provision sub-clause （1）of this clause．

22．2業(yè)主必須保護承包人不因與本條第1款規(guī)定事項有關的一切索賠、訴訟、損害賠償金、訴訟費、開支和費用而受損失。

23．（1）before commencing the execution of the works the contractor，but without limiting

his obligations and responsibilities under clause 22 hereof，shall insure against his liability for anymaterial or physical damage，loss or injury which may occur to any property，including that of the employer，or to any person，including any employee of the employer，by or arising out of the

execution of the works or in the carrying out of the contract，otherwise than due to the matters referred to in the provision clause 22（1）hereof．

23．1在開工前，在不減少本合同第22條規(guī)定給他的義務和責任條件下，承包人必須對任何可能由于或因施工或因履行本合同而給包括業(yè)主的財產(chǎn)在內(nèi)的任何財產(chǎn)，以及給包括業(yè)主的雇員在內(nèi)的任何人員造成的重大或實質性損害、損失或傷害進行責任保險，本合同第22條規(guī)定的事項除外。

（2）such insurance shall be effected with an insurer and in terms approved by the employer，which approval shall not be unreasonably withheld，and for at least the amount stated in the appendix to the tender．the contractor shall，whenever required，produce to the engineer or the engineer's representative the policy or policies of insurance and the receipts for payment of

the current premiums．

23．2此種保險必須在一保險公司投放，條款得經(jīng)業(yè)主認可，業(yè)主不得無故不同意投保，保險金額不得少于標書附件規(guī)定的數(shù)額。承包人必須隨時應要求向工程師或工程師代表出示保險單和支付現(xiàn)行保險費的收據(jù)。

（3）the terms shall include a provision whereby，in the event of any claim in respect of which the contractor would be entitled to receive indemnity under the policy being brought or made against the employer，the insurer will indemnify the employer against such claims and any costs，charges and expenses in respect thereof．

23．3保險條款中必須規(guī)定，承包人不得對可能得到保險賠償?shù)挠嘘P事項對業(yè)主提出任何索賠，保險公司應保護業(yè)主免受索賠損失，且賠償其有關的任何訴訟費及開支和費用。

24．（1）the employer shall not be liable for or in respect of any damages or compensation payable at law in respect or in consequence of any accident or injury to any workman or other person in the employment of the contractor or any sub-contractor，save and except an accident or injury resulting from any act or default of the employer，his agents，or servants． the contractor shall indemnify and keep indemnified the employer against all such damages and compensation， save and except as aforesaid，and against all claims，proceedings，costs，charges and expenses whatsoever in respect thereof or in relation thereto．

24．1業(yè)主不對因承包人或任何轉包人的工人或其他雇用人員的任何事故或傷害而根據(jù)法律應予支付的任何賠償金負責，除非事故或傷害是由業(yè)主、其代理人或雇員的任何行為或玩忽職守引起的。除上述規(guī)定外，承包人得保護業(yè)主不因所有此種損害賠償，以及因與此有關的所有索賠、訴訟、訴訟費、開支和費用而受損失。

（2）the contractor shall insure against such liability with an insurer approved by the employer，which approval shall not be unreasonably withheld，and shall continue such insurance

during the whole of the time that any persons are employed by him on the works and shall，when

required，produce to the engineer or the engineer's representative such policy of insurance and the receipt for payment of the current premium．provided always that，in respect of any persons employed by any sub-contractor，the contractor's obligation to insure as aforesaid under this sub-

clause shall be satisfied if the sub-contractor shall have insured against the liability in respect ofsuch persons in such manner that the employer is indemnified under the policy，but the contractor shall require such sub-contractor to produce to the engineer or the engineer's representative，when required，such policy of insurance and the receipt for the payment of the current premium．

24．2承包人必須就此種責任投保，保險公司得經(jīng)業(yè)主同意，業(yè)主不得無故不予同意，承包人必須在工地雇用工人的整個期間繼續(xù)保險，并隨時應要求向工程師或工程師代表出示此種保險單和支付現(xiàn)行保險費的收據(jù)。就任何轉包人所雇用的人員，如轉包人已經(jīng)就此種人員的責任投保，且以業(yè)主為保險補償對象，則承包人上述的投保義務得被視作已經(jīng)履行，但承包人必須要求此轉包人隨時應要求向工程師或工程師代表出示此種保險單和支付現(xiàn)行保險費的收據(jù)。

25．if the contractor shall fail to effect and keep in force the insurance referred to in clauses

21，23 and 24 hereof，or any other insurance which he may be required to effect under the terms of the contract，then and in any such case the employer may effect and keep in force any such insurance and pay such premium or premiums as may be necessary for that purpose and from time to time deduct the amount so paid by the employer as aforesaid from any monies due or which may become due to the contractor，or recover the same as a debt due from the contractor．

25．如果承包人未按本合同第21、23和24條的規(guī)定投保和繼續(xù)保險，或未按本合同條款規(guī)定就應由他投的其他任何保險進行投保，在任何此種情況下，業(yè)主可購買和繼續(xù)任何保險，支付此種必要的費用，且隨時從應付或可能應付給承包人的款項中將業(yè)主上述所支付的費用扣除，或將此作為承包人的負債追償。

26．（1）the contractor shall give all notices and pay all fees required to be given or paid by any national or state statute，ordinance，or other law，or any regulation，or by-law of any local or other duly constituted authority in relation to the execution of the works and by the rules and regulations of all public bodies and companies whose property or rights are affected or may be affected in any way by the works．

26．1承包人必須按國家或州一切有關施工的制定法、法令、或其他 法規(guī) 、或任何條例、或當?shù)鼗蚱渌戏ó斁值牡胤椒ㄒ?guī)以及所有其財產(chǎn)或權利受到或可能受到工程影響的公共團體和公司的規(guī)章制度的規(guī)定，發(fā)布所有的通告和支付所有的費用。

（2) the contractor shall conform in all respects with the provisions of any such statute，ordinance or law as aforesaid and the regulations or by-laws of any local or other duly constituted authority which may be applicable to the works and with such rules and regulations of public bodies and companies as aforesaid and shall keep the employer indemnified against all penalties and liability of every kind for breach of any such statute，ordinance or law，regulation or by-law．

26．2承包人必須遵守以上任何制定法、法令或法規(guī)，可適用于工程的當?shù)鼗蚱渌戏ó斁值囊磺械胤椒ㄒ?guī)，以及上述公共團體和公司的規(guī)章制度，如違反上述任何此種制定法、法令或法規(guī)、條例或地方法規(guī)，不得讓業(yè)主受任何懲罰和承擔任何責任。

（3）the employer will repay or allow to the contractor all such sums as the engineer shall certify to have been properly payable and paid by the contractor in respect of such fees．

26．3如工程師證實業(yè)主應償還已由承包人支付的此種費用，業(yè)主應償付或同意償付承包人所有此種金額。

27．a(chǎn)ll fossils，coins，articles of value or antiquity and structures and other remains or things of geological or archaeological interest discovered．the works shall as between the employer and the contractor be deemed to be the absolute property of the employer．the contractor shall take reasonable precautions to prevent his workmen or any other persons from removing or damaging any such article or thing and shall immediately upon discovery thereof and，befor lemoval，acquaint the engineer's representative of such discovery and carry out，at the expense of the employer，the engineer's representative's orders as to the disposal of the same．

27．所有在工地發(fā)現(xiàn)的化石、錢幣、有價值的物品或古物、建筑物和其他具有地質或考古價值的遺址或物品，均應被業(yè)主和承包人共同認定為是業(yè)主的絕對財產(chǎn)。承包人必須采取恰當?shù)拇胧乐蛊涔と嘶蚱渌魏稳宿D移或破壞任何此種物品，并在物品發(fā)現(xiàn)后不得轉移，立即通知工程師代表并執(zhí)行工程師代表的有關處置命令，其費用由業(yè)主承擔。

28．the contractor shall save harmless and indemnify the employer from and against all claims and proceedings for or on account of infringement of any patent rights，design，trademark or name or other protected rights in respect of any constructional plant，machine work，or material used for or in connection with the works or any of them and from and against all claims， proceedings，damages，costs，charges and expenses whatsoever in respect thereof or in relation thereto． except where otherwise specified，the contractor shall pay all tonnage and other royalties，rent and other payments or compensation，if any，for getting stone，sand，gravel clay or other materials required for the works or any of them．

28．承包人必須保護業(yè)主不得因在工程或部分工程中使用或涉及到任何建筑設備、機械加工、或材料，從而侵犯與之有關的 專利權 、外觀設計、 商標 或商號或其他應受保障的權利而遭索賠或被起訴，并必須保護業(yè)主免受與此有關的任何索賠、訴訟、損害賠償金、訴訟費、支出或費用的損害。除另有規(guī)定外，承包人必須承擔工程或部分工程所需的石頭、沙子、砂礫、泥土或其他材料的運費、沙石產(chǎn)地使用費、租金和其他費用或補償（如果有）。

29．a(chǎn)ll operations necessary for the execution of the works shall，so far as compliance with the requirements of the contract permits，be carried on so as not to interfere unnecessarily or improperly with the convenience of the public，or the access to，use and occupation of public or private roads and footpaths to or of properties whether in the possession of the employer or of any other person．the contractor shall save harmless and indemnify the employer in respect of all claims, proceedings，damages，costs，charges and expenses whatsoever arising out of，or in relation to，any such matters in so far as the contractor is responsible therefor．

29．所有施工必需的活動，凡符合合同許可證的規(guī)定，必須開展，從而保證不無故妨礙公眾的便利，或妨礙公共或私人道路的通行、使用和占用，無論道路是通向或是在業(yè)主或其他人的地產(chǎn)上。倘若發(fā)生此類應由承包人負責的事件，承包人必須保護業(yè)主免受由此而引而起的任何索賠、訴訟、損害賠償費、訴訟費、開支和費用的損害。

30．（1）the contractor shall use every reasonable means to prevent any of the highways or bridges communicating with or on the routes to the site from being damaged or injured by any traffic of the contractor or any of his sub一contractors and，in particular，shall select routes, choose and use vehicles and restrict and distribute loads so that any such extraordinary traffic as will inevitably arise from the moving of plant and material from and to the site shall be limited asfar as reasonably possible，and so that no unnecessary damage or injury may be occasioned to such highways and bridges．

30．1承包人必須采取各種合理手段，防止連接或通向工地的任何公路或橋梁由于承包人或其任何轉包人的使用而遭受損害，承包人尤其必須挑選路線、選擇使用車輛，限制和分散裝載量，從而使因往來于工地的設備和材料的運輸而必然造成的異常交通盡可能地被合理限

制，由此避免對公路和橋梁造成不必要的損害。

（2）should it be found necessary for the contractor to move one or more loads of constructional plant，machinery or pre一constructed units or parts of units of work over part of a highway or bridge，the moving whereof is likely to damage any highway or bridge unless special protection or strengthening is carried out，then the contractor shall before moving the load on to such highway or bridge give notice to the engineer or engineer's representative of the weight and other particulars of the load to be moved and his proposals for protecting or strengthening the said highway or bridge．unless within fourteen days of the receipt of such notice the engineer shall by counternotice direct that such protection or strengthening is unnecessary，then the contractor will carry out such proposals or any modification thereof that the engineer shall require and，unless there is an item or are items in the bill of quantities for pricing by the contractor of the necessary works for the protection or strengthening aforesaid，the costs thereof shall be paid by the employer to the contractor．

30．2如承包人必須經(jīng)部分公路或橋梁一次或多次運送建筑設備、機械或工程預制件或預制部件，如不采取特殊保護和加固措施，此種運送很可能損壞公路或橋梁，承包人運送貨物通過此公路或橋梁前必須通知工程師或工程師代表，告之運送貨物的重量及其他具體情況，以及其擬對上述公路或橋梁采取的保護和加固措施。除非在接到通知14天內(nèi)，工程師以取消通知的方式指示不必采取此種保護或加固措施，承包人將施行此種方案或施行經(jīng)工程師要求修改后的方案，除非建筑工程清單中含有一項或多項已由承包人標價的上述公路或橋梁保護或加固的必要項目，其費用得由業(yè)主向承包人支付。

（3） if during the execution of the works or at any time thereafter the contractor shall receive any claim arising out of the execution of the works in respect of damage or injury to highways or bridges he shall immediately report the sums to the engineer and thereafter the employer shall negotiate the settlement of and pay all sums due in respect of such claim and shall indemnify the contractor in respect thereof and in respect of all claims，proceedings，damages，costs，charges and expenses in relation thereto． provided always that if and二far as any such claims or part thereof shall in the opinion of the engineer be due to any failure on the part of the contractor to observe and perform his obligations under sub-clauses（1) and（2）of this clause，then the amount certified by the engineer to be due to such failure shall be paid by the contractor to the employer．

30．3如果在施工期間或以后任何時間，承包人因施工損壞公路或橋梁而被索賠，他必須立即報告工程師，其后，業(yè)主將商洽解決并支付索賠款，并保護承包人免受該索賠以及與之有關的一切索賠、訴訟、損害賠償金、訴訟費、開支和費用的損害。如果工程師認為造成此種索賠或部分索賠的原因在于承包人沒有履行本條第1款和第2款規(guī)定的義務，由工程師確認的因此種不履行而損失的款額必須由承包人支付給業(yè)主。

（4）where the nature of the works is such as to require the use by the contractor ofwaterborne transport the foregoing provisions of this clause shall be construed as though “highway' included a lock，dock，sea wall or other structure related to a waterway and“vehicle' included craft，and shall have effect accordingly．

30．4如果工程性質需要承包人使用水路運輸，本條上述規(guī)定必須按“公路”包括船閘、碼頭、防波堤或其他有關的水路設施，“運輸工具”包括船只來予以解釋，并由此而施行。

31．the contractor shall，in accordance with the requirements of the engineer，afford all reasonable opportunities for carrying out their work to any other contractors employed by the employer and their workmen and to the workmen of the employer and of any other duly constituted authorities who may be employed in the execution on or near the site of any work not included in the contract or of any contract which the employer may enter into in connection with or auxiliary to the works．if，however，the contractor shall，on the written request of the engineer or the engineer's representative，make available to any such other contractor，or to the employer or any such authority，any roads or ways for the maintenance of which the contractor is responsible，or permit the use by any such of the contractor's scaffolding or other plant on the site，or provide any other service of whatsoever nature for any such，the employer shall pay to the contractor in respect of such use or service such sum or sums as shall，in the opinion of the engineer，be reasonable，

31．承包人必須按工程師的要求，為業(yè)主雇用的其他承包商及其工人，以及為業(yè)主或其他合法當局雇用的工人提供合理開展工作的機會，這些工人可受雇在工地上或附近，從事不為本合同規(guī)定的任何工作或由業(yè)主簽訂的與工程有關或附屬工程的任何其他合同規(guī)定的工作。然而，如承包人應工程師或工程師代表的書面要求，為其他承包人、業(yè)主或其他合法當局提供由他負責維護的道路，或準許使用其在工地的腳手架或其他設備，或提供其他任何類似性質的服務，業(yè)主必須向承包人支付有關此種使用或服務的費用，只要工程師認為合理。

32．during the progress of the works the contractor shall keep the site reasonably free from all unnecessary obstruction and shall store or dispose of any constructional plant and surplus materials and clear away and remove from the site any wreckage，rubbish or temporary works no longer required．

32．在施工期間，承包人應保證工地沒有任何不必要的障礙物，妥善儲存或處置建筑設備和多余的材料，將所有殘余物垃圾或不再需要的臨時工程設施清理出工地。

33．on the completion of the works the contractor shall clear away and remove from the site all constructional plant，surplus materials，rubbish and temporary works of every kind，and leave the whole of the site and works clean and in a workmanlike oondition to the satisfaction of the engineer．

33．完工之后，承包人應將所有建筑設備、多余材料、垃圾和各種臨時工程設施清理出工地，使整個工地和工程顯得整潔合乎標準，讓工程師滿意。

labor

勞工

34．（1）the contractor shall make his own arrangements for the engagement of all labor，local or otherwise，and save insofar as the contract otherwise provides，for the transport，housing feeding and payment thereof．

34．1承包人必須自己安排雇用所有當?shù)鼗蚱渌胤降膭诠?，并負責勞工的交通、食宿?工資 ，本合同另有規(guī)定的除外。

（2）the contractor shall，so far as is reasonably practicable，having regard to local conditions，provide on thesite，to the satisfaction of the engineer's representative，an adequate supply of drinking and other water for the use of the contractor's staff and work people．

34．2只要合理可行，承包人應視當?shù)厍闆r，向工地的職員和工人提供充足的飲水和其他用水，讓工程師代表感到滿意。

（3）the contractor shall not，otherwise than in accordance with the statutes，ordinances and government regulations or orders for the time being in force，import，sell，give，barter or otherwise dispose of any alcoholic liquor，or drugs，or permit or suffer any such importation，sale，gift，barter or disposal by his sub-contractors，agents or employees．

34．3除非根據(jù)現(xiàn)行法律、法規(guī)及政府規(guī)章或命令，承包人不得進口、銷售、贈予、以物交換或以其他方式處置任何烈酒或毒品，或允許或容忍轉包人、代理人或雇員參與任何此種物品的進口、銷售、贈予、交換或處置。

（4）the contractor shall not give，barter or otherwise dispose of to any person or persons，any arms or ammunition of any kind or permit or suffer the same as aforesaid．

34．4如上所述，承包人不得向他人贈予、交換或以其他方式處置任何武器或彈藥，也不得準許或容忍同樣行為發(fā)生。

（5）the contractor shall in all dealings with labor in his employment have due regard to allrecognized festivals，days of rest and religious or other customs．

34．5在處理與雇工的關系時，承包人應適當注意公認的節(jié)假日和宗教或其他習俗。

（6） in the event of any outbreak of illness of an epidemic nature，the contractor shall comply with and carry out such regulations，orders and requirements as may be made by the government，or the local medical or sanitary authorities for the purpose of dealing with and overcoming the same．

34．6一旦爆發(fā)傳染病，承包人必須遵守并執(zhí)行政府或當?shù)蒯t(yī)療衛(wèi)生機構為治療此種疾病所制定的規(guī)章、命令及要求。

（7）the contractor shall at all times take all reasonable precautions to prevent any unlawful， riotous or disorderly conduct by or amongst his employees and for the preservation of peace and protection of persons and property in the neighborhood of the works against the same．

34．7承包人應隨時采取一切合理的預防措施，防止其雇員制造或在雇員中發(fā)生違法、騷亂或混亂行為，以維護治安和保護工程附近地區(qū)人員和財產(chǎn)的安全。

（8）the contractor shall be responsible for observance by his sub-contractors of the foregoing provisions．

34．8承包人必須負責讓其轉包人遵守上述規(guī)定。

（9）any other conditions affecting labor and wages shall be as set out in partⅱin the clause numbered 34 as may be necessary．

34．9如有必要，可在第二部分的第34條就所有其他有關勞工和工資的條件作出規(guī)定。

35．the contractor shall，if required by the engineer，deliver to the engineer representative，or at his office，a return in detail in such form and at such intervals as theengineer may prescribe showing the supervisory staff and the numbers of the several classes of labor from time to time employed by the contractor on the site and such information respecting constructional plant as the engineer's representative may require．

35．如工程師要求，承包人應按工程師要求的格式和時間向工程師代表或其辦公室提交一份詳細報告，匯報其在工地隨時雇用的監(jiān)督人員和不同等級勞工的數(shù)量，以及工程師代表可能要求的有關建設設備的情況。

materials and worship

材料和工藝

36．（1）all materials and workmanship shall be of the respective kinds described in the contract and in accordance with the engineer's instructions and shall be subjected from time to time to such tests as the engineer may direct at the place of manufacture or fabrication，or on the site or at such other place or places as may be specified in the contract，or at all or any of such places． the contractor shall provide such assistance，instruments，machines，labor and materials as are normally required for examining，measuring and testing any work and the quality，weight or quantity of any material used and shall supply samples of materials before incorporation in the works for testing as may be selected and required by the engineer．

36．1所有材料和工藝均應符合合同的規(guī)定和工程師的指令，且應隨時在制造或加工地、工地或合同具體規(guī)定的其他地點，同時或在某一處，接受工程師可能命令進行的檢驗。承包人要為任何工程或任何材料的質量、重量或數(shù)量的檢查、測量和檢驗提供正常所需的幫助、工具、機械、勞力和材料，承包人還必須應工程師可能的選擇和要求，在材料應用于工程之前提供材料樣品以供檢驗。

（2）all samples shall be supplied by the contractor at his own cost if the supply thereof is

clearly intended by or provided for in the contract，but if not，then at the cost of the employer．

36．2如合同明顯默示或明文規(guī)定，所有由承包人提供的樣品的費用應由承包人自己承擔，否則應由業(yè)主支付。

（3）the cost of making any test shall be borne by the contractor if such test is clearly intended by or provided for in the contract and，in the cases only of a test under load or of a test to ascertain whether the design of any finished or partially finished work is appropriate for the purposes which it was intended to fulfil，is particularized in the contract in sufficient detail to enable the contractor to price or allow for the same in his tender．

36．3如合同明顯默示或明文規(guī)定，一切檢驗費用應由承包人負擔，對于僅是負載檢測和確認任何完成或部分完成的工程之設計是否符合要求的檢驗，本合同作有詳盡規(guī)定，可確?；驕试S承包商將其費用計人投標價格中。

（4）if any test is ordered by the engineer which is either．

36．4凡是工程師命令所作的檢驗，而

（a）not、intended by or provided for，or

合同沒有默示或規(guī)定，或

（b）（in the cases above mentioned）is not so particularized，or

（在上述情況中）沒有如此詳細規(guī)定，或

（c）though so intended or provided for is ordered by the engineer to be carried out by an independent person at any place other than the site or the place of manufacture or fabrication of the materials tested，

雖有默示或規(guī)定，但卻是由工程師命令獨立個人在工地之外，或在該檢驗物資的制造或加工地之外的任何地點進行的，

then the cost of such test shall be borne by the contractor，if the test shows the workmanship or materials not to be in accordance with the provisions of the contract or the engineer's instructions，but otherwise by the employer．

如檢驗結果表明工藝或材料不符合合同規(guī)定或工程師指令，檢驗費由承包人承擔，否則由業(yè)主支付。

37．the engineer and any person authorized by him shall at all times have access to the works and to all workshops and places where work is being prepared or from where materials， manufactured articles or machinery are being obtained for the works and the contractor shall afford every facility for and every assistance in or in obtaining the right to such access．

37．工程師和他授權的任何人隨時有權到工程現(xiàn)場，到任何工程準備地或工程所需材料、制品或機械獲得地，承包人應為其行使或獲得此種到場權利提供一切便利和幫助。

38．（1）no work shall be covered up or put out of view without the approval of the engineer or the engineer's representative and the contractor shall afford full opportunity for the engineer or the engineer's representative to examine and measure any work which is about to be covered up or put out of view and to examine foundations before permanent work is placed thereon．the contractor shall give due notice to the engineer's representative whenever any such work or foundations is or are ready or about to be ready for examination and the engineer's representative shall，without unreasonable delay，unless he considers it unnecessary and advises the contractor accordingly，attend for the purpose of examining and measuring such work or of examining suchfoundations．

38．1未經(jīng)工程師或工程師代表的認可，任何工程不得被覆蓋或遮掩，承包人應為工程師或工程師代表提供充分機會，以檢查和測量即將被覆蓋或遮掩的任何工程，以及在永久性工程開始前檢查地基。承包人應在任何此種工程或地基做好或即將做好檢查準備時及時通知工程師代表，工程師代表必須參加此種工程或地基的檢查，不得無故拖延，除非他認為檢查沒有必要，且由此通知承包人。

（2）the contractor shall uncover any part or parts of the works or make openings in or through the same as the engineer may from time to time direct and shall reinstate and make good such part or parts to the satisfaction of the engineer．if any such part or parts have been covered

up or put out of view after compliance with the requirement of sub-clause（1）of this clause and

are found to be executed in accordance with the contract，the expenses of uncovering，making

openings in or through，reinstating and making good the same shall be borne by the employer，

but in any other case all costs shall be borne by the contractor．

38．2承包人必須應工程師隨時作出的指示，打開業(yè)已覆蓋的工程某一或某些部分，或在工程上或經(jīng)過工程開通道，并負責使之完好復原而讓工程師滿意。凡任何此種工程部分是在履行本條第1款之規(guī)定后被覆蓋或遮掩的，則打開和在工程上或經(jīng)過工程開通道，以及使之完全復原的費用由業(yè)主承擔，否則所有費用應由承包人承擔。

39．（1）the engineer shall during the progress of the works have power to order in writing

from time to time：

39．1在施工中，工程師有權隨時書面命令：

（a) the removal from the site，within such time or times as may be specified in the order，

of any materials which，in the opinion of the engineer，are not in accordance with the contract，

把工程師認為不符合合同規(guī)定的任何材料按命令中具體規(guī)定的時間從工地換走，

（b）the substitution of proper and suitable materials and，

用恰當合適的材料予以替換和

（c）the removal and proper re-execution，notwithstanding any previous test thereof or interim payment therefor，of any work which in respect of materials or workmanship is not，in the opinion of the engineer，in accordance with the contract．

把工程師認為不符合合同規(guī)定的材料或工藝換掉或適當重新施工，無論其在之前是否經(jīng)過檢查或作過中期支付。

（2）in case of default on the part of the contractor in carrying out such order，the employer shall be entitled to employ and pay other persons to carry out the same and all expenses consequent hereon or incidental thereto shall be recoverable from the contractor by the employer，or may be deducted by the employer from any monies due or which may become due to the contractor．

39．如承包人未執(zhí)行此種命令，業(yè)主有權雇用他人執(zhí)行，業(yè)主應從承包人處收回由此而產(chǎn)生的所有費用和雜費，或從應付給或即將付給承包商的款項中予以扣除。

40．（1）the contractor shall，on the written order of the engineer，suspend the progress of the works or any part thereof for such time or times and in such manner as the engineer may consider necessary and shall during such suspension properly protect and secure the work，so far as is necessary in the opinion of the engineer．the extra cost incurred by the contractor in giving effect to the engineer's instructions under this clause shall be borne and paid by the employer unless such suspension is：

40．1收到工程師的書面命令后，承包人必須在工程師認為必要的時間，以其認為必要的方式，停止工程或部分工程的施工，只要工程師認為必要，還必須在停工期間妥善保護工程的安全。承包人根據(jù)本條款執(zhí)行工程師指令而發(fā)生的額外費用應由業(yè)主承擔，除非此種停工是：

（a）otherwise provided for in the contract，or

合同另行規(guī)定的，或

（b）necessary by reason of some default on the part of the contractor，or

由承包人的某種違約而導致的必要停工，或

（c) necessary by reason of climatic conditions on the site，or

由工地的氣候條件導致的必要停工，或

（d）necessary for the proper execution of the works or for the safety of the works or anypart thereof insofar as such necessity does not arise from any act or default by the engineer or the employer or from any of the excepted risks defined in clause 20 hereof．

為正常施工或為整個工程或部分工程的安全而作的必要停工，而不是因工程師或業(yè)主的任何行為或違約而產(chǎn)生的，也不是因本合同第20條規(guī)定的任何除外風險引起的。

provided that the contractor shall not be entitled to recover any such extra cost unless he gives written notice of his intention to claim to the engineer within days of the engineer's order．the engineer shall settle and determine such extra payment and/or extension of time under clause 44 hereof to be made to the contractor in respect of such claim as shall，in the opinion of the engineer，be fair and reasonable．

承包人在收到工程師命令后xx天內(nèi)應書面通知工程師，要求賠償，否則將無權得到額外費用。如工程師認為承包人的要求公平合理，他必須按本合同第44條的規(guī)定，處理并決定此種支付給承包人的額外費用和／或停工時間。

（2）if the progress of the works or any part thereof is suspended on the written order of the engineer and if permission to resume work is not given by the engineer within a period of ninety days from the date of suspension then，unless such suspension is within paragraph（a)，（b），（c） or（d）of sub—clause（1）of this clause，the contractor may serve a written notice on the engineer requiring permission within days from the receipt thereof to proceed with the works，or that part thereof in regard to which progress is suspended and，if such permission is not granted within that time，the contractor by a further written notice so served may，but is not bound to，elect or treat the suspension where it affects part only of the works as an omission of such part under clause 51 hereof，or，where it affects the whole works，as an abandonment of the contract by the employer．

40．2如整個工程或部分工程按工程師的命令停工，且停工90天后仍未得到工程師作出的復工命令，除非此種停工屬本條第1款第1、2,3或4項規(guī)定范圍之內(nèi)，否則承包人可書面通知工程師，要求其在收到通知后xx天內(nèi)準許對整個工程，或停工的部分工程重新開工，如在此期間仍未獲得開工許可，承包人可以，但不一定必須再作書面通知，按本合同第51條的規(guī)定將只影響到部分工程的停工視為是對該部分工程的省略，或，如停工影響到整個工程，視其為是業(yè)主廢棄合同。

commencement time and delays

開工時間和延誤

41．the contractor shall commence the works on site within the period named in the appendix to the tender after the receipt by him of a written order to this effect from the engineer and shall proceed with the same with due expedition and without delay，except as may be expressly sanctioned or ordered by the engineer，or be wholly beyond the contractor's control．

41．接到工程師的書面開工通知后，承包人應在標書附錄中規(guī)定的期限內(nèi)在工地施工，且必須迅速，不得延誤，工程師明文同意或命令，或承包人無法控制的原因除外。

42．（1）save insofar as the contract may prescribe，the extent of portions of the site of which the contractor is to be given possession from time to time and the order in which such portions shall be made available to him and，subject to any requirement in the contract as to the order in which the works shall be executed，the employer will，with the engineer's written order to commence the works，give to the contractor possession of so much of the site as may berequired to enable the contractor to commence and proceed with the execution of the works in accordance with the program referred to in clause 14 hereof，if any，and otherwise in accordance with such reasonable proposals of the contractor as he shall，by written notice to the engineer， make and will，from time to time as the works proceed，give to the contractor possession of such further portions of the site as may be required to enable the contractor to proceed with the execution of the works with due dispatch in accordance with the said program or proposals，as the case may be，if the contractor suffers delay or incurs cost from failure on the part of the employer to give possession in accordance with the terms of this clause，the engineer shall grant an extension of time for the completion of the works and certify such sum as，in his opinion，shall be fair to cover the cost incurred，which sum shall be paid by the employer．

42．1除合同另有規(guī)定的外，就承包人應隨時獲得的工地的范圍及授權他使用此部分工地的命令而言，業(yè)主應根據(jù)合同有關施工命令的規(guī)定，隨同工程師的書面開工命令，提供承包人必要范圍的工地，使其能夠開始并按本合同第14條規(guī)定的方案施工，此外應根據(jù)承包人給工程師的書面通知上的合理建議（如果有），在施工期間隨時向承包人提供更大范圍的地，以保證承包人能按上述方案或建議迅速施工。如承包人因業(yè)主不按本條規(guī)定提供工地而誤工或發(fā)生費用，工程師應準許延長工期，并由他確定一筆補償此種費用的款項，該款項應由業(yè)主支付。

（2） the contractor shall bear all costs and charges for special or temporary way leaves required byhim in connection with acoess to the site． the contractor shall also provide at his own cost any additional accommodation outside the site required by him for the purposes of the works．

42．2承包人應承擔因通往工地的所有特殊或臨時道路通行權而產(chǎn)生的費用。承包人也得支付為施工而應他的要求在工地之外食宿而發(fā)生的一切額外費用。

43．subject to any requirement in the contract as to completion of any section of the works before completion of the whole，the whole of the works shall be completed，in accordance with the provisions of clause 48 hereof，within the time stated in the contract calculated from the last day of the period named in the appendix to the tender as that within which the works are to be commenced，or such extended time as may be allowed under clause 44 hereof．

43．除按合同規(guī)定，工程整體完工前任何部分工程必須按時完工外，根據(jù)合同第48條的規(guī)定，整個工程必須在合同規(guī)定的期限內(nèi)完成，該期限應從標書附錄規(guī)定的開工期的最后一天算起，或以本合同第44條的規(guī)定而準許的延期時間為準。

44．should the amount of extra or additional work of any kind or any cause of delay referred to in these conditions，or exceptional adverse climatic conditions，or other special circumstances of any kind whatsoever which may occur，other than through a default of the contractor，be such as fairly to entitle the contractor to an extension of time for the completion of the works，the engineer shall determine the amount of such extension and shall notify the employer and the contractor accordingly．provided that the engineer is not bound to take into account any extra or additional work or other special circumstances unless the contractor has within days after such work has been commenced，or such circumstances have arisen，or as soon thereafter as is practicable, submitted to the engineer's representative full and detailed particulars of any extension of time to which he may consider himself entitled in order that such submission may be investigated at the time．

44．除承包人違約外，如因額外工程或工程量的增加或由此而涉及的任何延誤原因、或特別惡劣的氣候、或其他可能發(fā)生的任何特殊情況而使得承包人有權要求工程延期，工程師應決定延期時間，并由此通知業(yè)主和承包人。如承包人在此種工程開工后、或此種情況一發(fā)生、或按實情在其發(fā)生后的xx天內(nèi)，沒有向工程師代表提交詳細說明他認為有權延期的報告而讓此陳述當時便得到調查，工程師可不予考慮額外工程或工程量的增加或其他特殊情況。

45．subject to any provision to the contrary contained in the contract，none of the permanent works shall，save as hereinafter provided，be carried on during the night or on sundays，if locally recognized as days of rest，or their locally recognized equivalent without the permission in writing of the engineer's representative，except when the work is unavoidable or absolutely necessary for the saving of life or property or for the safety of the works，in which case the contractor shall immediately advise the engineer's representative．provided always that the provisions of this clause shall not be applicable in the case of any work which it is customary to carry out by rotary or double shifts．

45．除合同另有相反規(guī)定外，未經(jīng)工程師代表的書面允許，任何永久性工程不得在夜間或星期天進行，只要這些時間在當?shù)乇徽J作是假日，同時也不得在其他被當?shù)卣J作是假日的時間進行，但下列情況除外：因工程而不得已或為挽救生命、財產(chǎn)或維護工程安全而絕對必要，在這種情況下，承包商應立即通知工程師代表。本條的規(guī)定不適用于按傳統(tǒng)需輪班或倒班進行的工作。

46．if for any reason，which does not entitle the contractor to an extension of time，the rate of progress of the works or any section is at any time，in the opinion of the engineer，too slow to ensure completion by the prescribed time or extended time for completion，the engineer shall so notify the contractor in writing and the contractor shall thereupon take such steps as are necessary and the engineer may approve to expedite progress so as to complete the works or such section by the prescribed time or extended time．the contractor shall not be entitled to any additional payment for taking such steps．if，as a result of any notice given by the engineer under this clause，the contractor shall seek the engineer's permission to do any work at night or on sundays，if locally recognized as days of rest，or their locally recognized as days of rest，or their locally recognized equivalent，such permission shall not be unreasonably refused．

46．不論是何原因使得工程或其任何部分的進度讓工程師覺得太慢，因而無法確保在規(guī)定或延長期限內(nèi)完工，只要該原因不至于讓承包人有權要求延期，工程師必須書面通知承包人，接到通知后承包人應采取必要的措施，工程師可同意加快進度，以便能在規(guī)定或延長期限內(nèi)完工或完成某部分工程。承包人無權因采取此種措施而要求額外付款。如因工程師按本條款所作的通知的緣故，承包人需要求工程師準許在夜間或星期日，如果其在當?shù)乇划斪黾偃眨蛟谄渌划數(shù)禺斪鍪羌偃盏臅r間工作，工程師不得無故不準許。

47．（1）if the contractor shall fail to achieve completion of the works within the time prescribed by clause 43 hereof，then the contractor shall pay to the employer the sum stated in the contract as liquidated damages for such default and not as a penalty for every day or part of a day which shall elapse between the time prescribed by clause 43 hereof and the date of certified completion of the works．the employer may，without prejudice to any other method of recovery，deduct the amount of such damages from any monies in his hands，due or which may become due to the contractor．the payment or deduction of such damages shall not relieve thecontractor from his obligation to complete the works，or from any other of his obligations and liabilities under the contract．

47．1如承包人未在本合同第43條規(guī)定的期限內(nèi)完成工程，承包人應因違約而向業(yè)主支付合同所規(guī)定之款額，此款額為定額賠償金，而不是根據(jù)第43條規(guī)定的期限與實際完工時間之差按天數(shù)進行處罰。業(yè)主可在不損害其他收款措施的情況下，從他手中掌握的應支付或將支付給承包人的款項中扣除此種賠償金。此種賠償金的支付或扣除不得免除承包人完成工程的義務，或免除他的其他任何合同所規(guī)定的責任和義務。

（2）if，before the completion of the whole of the works any part or section of the works has been certified by the engineer as completed，pursuant to clause 48 hereof，and occupied or used by the employer，the liquidated damages for delay shall，for any period of delay after such certificate and in the absence of alternative provisions in the contract be reduced in the proportion which the value of the part or section so certified bears to the value of the whole of the works．

47．2在工程全部完工前，如有某部分工程已由工程師按本合同第48條確認為完工，且已被業(yè)主占用，如在此后出現(xiàn)任何延誤，而本合同又無另行規(guī)定，因延誤本應處罰的定額賠償金則應按已完工的工程的價值所占全部工程價值的比例予以扣減。

（3）if it is desired to provide in the contract for the payment of a bonus in relation to completion of the works or of any part or section thereof this shall be set out in part ii in the clause numbered．

47．3如要在合同中規(guī)定有關工程全部或部分完工的獎勵支付事項，此規(guī)定應列在第二部分的第47條中。

48．（1）when the whole of the works have been substantially completed and have satisfactorily passed any final test that may be prescribed by the contract，the contractor may give a notice to that effect to the engineer or to the engineer's representative accompanied by an undertaking to finish any outstanding work during the period of maintenance．such notice and undertaking shall be in writing and shall be deemed to be a request by the works．the engineer shall，within _______days of the date of delivery of such notice either issue to the contractor，with

a copy to the employer，a certificate of completion stating the date on which，in his opinion，the

works were substantially completed in accordance‘with the contract or give instructions in writing to the contractor specifying all the work which，in the engineer's opinion，requires to be done by the contractor before the issue of such certificate．the engineer shall also notify the contractor of any defects in the works affecting substantial completion that may appear after sucb instructions and before completion of the works specified therein．the contractor shall be entitled to receive such certificate of completion within _______ days of completion to the satisfaction of the engineer of the works so specified and making good any defects so notified，

48．1當工程全部完工且滿意地通過了所有合同規(guī)定的最后檢驗后，承包人可向工程師或工程師代表發(fā)出有關通知，并承諾在維修期內(nèi)將完成任何未完成的工作。此種通知和承諾必須作成書面形式，且應被視作是承包人要工程師發(fā)放工程竣工證書的要求。工程師應在此種通知送出后_______天內(nèi)或向承包人發(fā)出工程竣工證書，并交業(yè)主一本副本，注明他認為工程已按合同規(guī)定圓滿完工的日期，或向承包人發(fā)出書面指示，具體說明他認為在發(fā)放此種證書前承包人還需完成的一切工作。在發(fā)出此種指示后，工程師還應通知承包人關于此后以及在指示中所提及之工程完工前，可能出現(xiàn)且會影響工程實際完工的任何欠缺。在令工程師滿意地完成所指明的工程并修正一切所指明的欠缺后，承包人有權在_______天之內(nèi)收到竣工證書。

（2）similarly，in accordance with the procedure set out in sub-clause（1）of this clause，the contractor may request and the engineer shall issue a certificate of completion in respect of：

48．2同樣，根據(jù)本條第1款規(guī)定的程序，就以下情況，承包人可要求，且工程師應頒發(fā)竣工證書：

（a）any section of the permanent works in respect of which a separate time for completion is provided in the contract and

合同中單獨作有完工期限規(guī)定的部分永久性工程竣工，以及

（b）any substantial part of the permanent works which has been both completed to the satisfaction of the engineer and occupied or used by the employer．

永久性工程的任何實體部分已竣工，令工程師滿意，且已被業(yè)主占有或使用。

（3）if any part of the permanent works shall have been substantially completed and shall have satisfactorily passed any final test that may be prescribed by the contract，the engineer may issue a certificate of completion in respect of that part of the permanent works before completion of the whole of the works and，upon the issue of such certificate，the contractor shall be deemed to have undertaken to complete any outstanding work in that part of the works during the period of maintenance．

48．3如部分永久性工程已實質性完工，且滿意地通過了合同規(guī)定的最后檢驗，工程師可在全部工程竣工前頒發(fā)此部分工程的竣工證書，一旦頒發(fā)此種證書，承包人應被視作已承諾在維修期內(nèi)完成此部分工程中一切尚未完成的工作。

（4）provided always that a certificate of completion given in respect of any section or part of the permanent works before completion of the whole shall not be deemed to certify completion of any ground or surfaces requiring reinstatement，unless such certificate shall expressly so state．

48．4在工程全部完工前就永久性工程的某一部分發(fā)放竣工證書，并不視為已經(jīng)完成任何所需的地面或地表還原工作，證書中明文規(guī)定的除外。

maintenance and defects

維修及欠缺

49．（1）in these conditions the expression 'period of maintenance' shall mean the period of maintenance named in the appendix to the tender，calculated from the date of completion of the works，certified by the engineer in accordance with clause 48 hereof，in the event of more than one certificate having been issued by the engineer under the said clause，from the respective dates so certified and in relation to the period of maintenance the expression“the works”shall be construed accordingly．

49．1本條款中“維修期”一詞指標書附錄所指的維修期，從工程師按本合同第48條規(guī)定確認的竣工日開始計算，如工程師根據(jù)上述條款發(fā)出了多份竣工證書，則分別從其確認的完工日開始計算，就維修期而言，“工程”一詞須作相應解釋。

（2）to the intent that the works shall at or as soon as practicable after the expiration of theperiod of maintenance be delivered to the employer in the condition required by the contract，fair wear and tear excepted，to the satisfaction of the engineer，the contractor shall finish the work， if any，outstanding at the date of completion，as certified under clause 48 hereof，as soon as practicable after such date and shall execute all such work of repair，amendment，reconstruction， rectification and making good defects，imperfections，shrinkage or other faults as may be required of the contractor in writing by the engineer during the period of maintenance，or within days after its expiration，as a result of an inspection made by or on behalf of the engineer prior to its expiration．

49．2為按合同規(guī)定條件在維修期滿時或其后盡快將工程交給業(yè)主，除合理損耗外，為讓工程師感到滿意，承包人必須盡快完成本合同第48條中規(guī)定的在完工日尚未完成的工作（如果有），以及完成工程師在維護期間，或在維護期滿后xx天內(nèi)，因工程師或工程師代表在維護期滿前的檢查而可能書面要求承包人完成的諸如修理、修正、再建、調整，以及修正欠缺、缺陷和其他毛病等一切工作。

（3）all such work shall be carried out by the contractor at his own expense if the necessity

thereof shall，in the opinion of the engineer，be due to the use of materials or workmanship not in

accordance with the contract，or to neglect or failure on the part of the contractor to comply with

any obligation，expressed or implied，on the contractor's part under the contract．if，in the

opinion of the engineer，such necessity shall be due to any other cause，the value of such work

shall be ascertained and paid for as if it were additional work．

49．3如工程師認為此種工作是因承包人使用的材料或工藝不符合合同的要求所致，或因承包人未履行其合同義務（明示或默示不論）所致，一切費用應由承包人承擔。如工程師認為此種需要是其他原因所致，則應對此種工作進行估價，并按附加工程支付。

（4）if the contractor shall fail to do any such work as aforesaid required by the engineer，the employer shall be entitled to employ and pay other persons to carry out the same and if such work is work which，in the opinion of the engineer，the contractor was liable to do at his own expense under the contract，then all expenses consequent thereon or incidental thereto shall be recoverable from the contractor by the employer，or may be deducted by the employer from any monies due or which may become due to the contractor．

49．4如承包人未完成工程師要求的上述此種工作，業(yè)主有權雇用他人完成，如工程師認為，按合同規(guī)定此工作本應由承包人自費完成，業(yè)主應向承包人追償由此發(fā)生的一切直接或間接費用，或從應付或可能應付給承包人的任何款項中予以扣除。

50．the contractor shall，if required by the engineer in writing，search under the directions of the engineer for the cause of any defect，imperfection or fault appearing during the progress of the works or in the period of maintenance．unless such defect，imperfection or fault shall be one for which the contractor is liable under the contract，the cost of the work carried out by the contractor in searching as aforesaid shall be borne by the employer． if such defect，imperfection or fault shall be one for which the contractor is liable as aforesaid，the cost of the work carried out in searching as aforesaid shall be borne by the contractor and he shall in such case repair，rectify and make good such defect，imperfection or fault at his own expense in accordance with tkv provisions of clause 49 hereof．

50．應工程師的書面要求，承包人應根據(jù)工程師的指令，對施工過程或維修期內(nèi)出現(xiàn)的任何欠缺、不足或缺陷進行檢查。除非根據(jù)合同，此種欠缺、不足或缺陷應由承包人負責，否則上述檢查工作的費用由業(yè)主承擔。如此種欠缺、不足或缺陷如上所述屬于承包人的責任，上述檢查費用應由承包人負擔，且他應按本合同第49條的規(guī)定，自費對其進行修理、修正和補救。

alterations，additions and omissions

變更、增加和省略

51．（1）the engineer shall make any variation of the form，quality or quantity of the works or any part thereof that may，in his opinion，be necessary and for that purpose，or if for any other reason it shall，in his opinion be desirable，he shall have power to order the contractor to do and the contractor shall do any of the following：

51．1如工程師認為必要，他應對整個工程或任何部分的形式、質量或工作量作相應變更，且他有權因其他任何理由，命令承包人作出且承包人必須作出以下變更：

（a） increase or decrease the quantity of any work included in the contract，

增減合同所規(guī)定的工程量，

（b）omit any such work，

省略任何部分工程，

（c) change the character or quality or kind of any such work，

改變?nèi)魏尾糠止こ痰奶匦曰蛸|量或類別，

（d）change the levels，lines，position and dimensions of any part of the works，and

改變?nèi)魏尾糠止こ痰钠矫?、型線、位置和面積，

（e）execute additional work of any kind necessary for the completion of the works

增加竣工所需的任何額外工程，

and no such variation shall in any way vitiate or invalidate the contract，but the value，if any，of all such variations shall be taken into account in ascertaining the amount of the contract price．

但此種變更不得以任何方式使合同失效，此種變更所需的一切費用（如果有）應在確定合同價格時予以考慮。

（2）no such variations shall be made by the contractor without an order in writing of the engineer．provided that no order in writing shall be required for increase or decrease in the quantity of any work where such increase or decrease is not the result of an order given under this clause，but is the result of the quantities exceeding or being less than those stated in the bill of quantities．provided also that if for any reason the engineer shall consider it desirable to give any such order verbally，the contractor shall comply with such order and any confirmation in writing of such verbal order given by the engineer，whether before or after the carrying out of the order， shall be deemed to be an order in writing within the meaning of this clause．provided further that if the contractor shall within _______ days confirm in writing to the engineer and such confirmation shall not be contradicted in writing within _______ days by the engineer，it shall be deemed to be an order in writing by the engineer．

51．2如無工程師的書面命令，承包人不得作任何此種變更。然而，如工程量的增減不屬本條規(guī)定的應作命令的范疇，而是因超過或不足建筑工程清單的規(guī)定所至，則不要求有書面命令。另外，如工程師因任何原因認為有必要口頭作此種命令，承包人必須服從，且工程師對該口頭命令的確認書，不論在命令執(zhí)行前或后給予，都應被視作是本條款所指的書面命令。此外，如承包人在_______天內(nèi)書面向工程師要求確認，而工程師在_______天內(nèi)未用書面駁回此確認，其應被視為是工程師所作的書面命令。

52．（1）all extra or additional work done or work omitted by order of the engineer shall be valued at the rates and prices set out in the contract if，in the opinion of the engineer，the same shall be applicable．if the contract does not contain any rates or prices applicable to the extra or additional work，then suitable rates or prices shall be agreed upon between the engineer and the contractor．in the event of disagreement the engineer shall fix such rates or prices as shall，in his opinion，be reasonable and proper．

52．1凡由工程師命令增減的工程，如工程師認為可行，均應按合同價格予以估價。如合同所列的價格不適用所增減的工程，應由工程師和承包人協(xié)商出合適的價格。如不能就此達成協(xié)議，應由工程師決定一個他認為恰當?shù)膬r格。

（2）provided that if the nature or amount of any omission or addition relative to the nature oramount of the whole of the works or to any part thereof shall be such that，in the opinion of the engineer，the rate or price contained in the contract for any item of the works is，by reason of such omission or addition，rendered unreasonable or inapplicable，then a suitable rate or price shall

be agreed upon between the engineer and the contractor．in the event of disagreement the engineer shall fix such other rate or price as shall，in his opinion，be reasonable and proper having regard to the circumstances、

52．2如工程師認為，涉及整個工程或部分工程的質或量的增減，使得本合同中所列的任何工程項目的價格因此種增減而不再合理或不切實際，工程師和承包人則應協(xié)商一個合適的價格。如不能就此達成協(xié)議，應由工程師決定一個他認為恰當?shù)膬r格。

provided also that no increase or decrease under sub-clause（1）of this clause or variation of rate or price under sub-clause（2）of this clause shall be made unless，as soon after the date of the order as is practicable and，in the case of extra or additional work，before the commencement of the work or as soon thereafter as is practicable，notice shall have been given in writing：

（a）by the contractor to the engineer of his intention to claim extra payment or a varied rate

or price，or

（b）by the engineer to the contractor of his intention to vary a rate or price．

除非在命令作出之后，如是額外或增加工程，則在工程動工前或之后盡快以書面形式：

a)由承包人通知工程師他要求額外支付或更改價格，

b)或由工程師通知承包人他打算改變價格，

否則不得按本條第1款增加或減少工程量，或按本條第2款變動價格。

（3）if，on certified completion of the whole of the works it shall be found that a reduction or increase greater than per cent of the sum named in the letter of acceptance，excluding allfixed sums，provisional sums and allowance for day works，if any，results from：

52．3竣工驗證時，如發(fā)現(xiàn)增減工程的費用超過驗收證書所注明數(shù)額的_______％，除去所有的規(guī)定費用、臨時費用和零工補貼外，如有任何是因：

（a) the aggregate effect of all variation orders，and

變動命令累計所致，以及因

（b）all adjustments upon measurement of the estimated quantities set out in the bill of quantities，excluding all provisional sums，day works and adjustments of price made under clause 70（1）hereof，

修正建筑工程清單所列的估算工程量所致，所有臨時費用、零工補貼和本合同第70條第1款規(guī)定的價格調整除外，

but not from any other cause，the amount of the contract price shall be adjusted by such sum as may be agreed between the contractor and the engineer or，failing agreement，fixed by the engineer having regard to all material and relevant factors，including the contractor's site and general overhead costs of the contract．

若非其他原因，合同價格應由承包人和工程師協(xié)商予以調整，或，如協(xié)商不果，則由工程師在考慮所有材料及相關的，包括承包人的場地及合同的一般間接費用在內(nèi)的因素的基礎上予以決定。

（4）the engineer may，if，in his opinion it is necessary or desirable，order in writing that

any additional or substituted work shall be executed on a day-work basis．the contractor shall

then be paid for such work under the conditions set out in the day-work schedule included in the

contract and at the rates and prices affixed thereto by him in his tender．

52．4如工程師認為有必要，可書面命令將增加或替換的工程按零工計價。此種工程承包人所得報酬應根據(jù)合同中的零工細目表的條件，按其標書中所附的價格予以支付。

the contractor shall furnish to the engineer such receipts or other vouchers as may be necessary to prove the amounts paid and，before ordering materials，shall submit to the engineer quotations for the same for his approval．

承包人應向工程師提供必要的收據(jù)或其他憑證以證實其支出，并應在訂材料之前，向工程師提交報價單以求批準。

in respect of all work executed on a day-work basis，the contractor shall，during the continuance of such work，deliver each day to the engineer's representative an exact list in duplicate of the names，occupation and time of all workmen employed on such work and a statement，also in duplicate，showing the description and quantity of all materials and plant used thereon or therefor（other than plant which is included in the percentage addition in accordance with the schedule hereinbefore referred to)．one copy of each list and statement will，if correct， or when agreed，be signed by the engineer's representative and returned to the contractor．

所有按零工計價的工程，在工程進行期間，承包人必須每天向工程師代表提供詳細清單，一式兩份，注明此種工程雇用的所有零工的姓名、職務和工作時間，以及兩份說明書，標明用于工程的材料和設備的規(guī)格、數(shù)量（按上述細目表納入增加費用計算內(nèi)的設備除外）。如清單和說明書正確無誤，工程師代表將認同且在其中一份上簽字，然后退還給承包人。

at the end of each month the contractor shall deliver to the engineer's representative a priced statement of the labor，material and plant，except as aforesaid，used and the contractor shall not be entitled to any payment unless such lists and statements have been fully andpunctually rendered．provided always that if the engineer shall consider that for any reason the sending of such lists or statements by the contractor，in accordance with the foregoing provision， was impracticable he shall nevertheless be entitled to authorize payment for such work，either as day-work，on being satisfied as to the time employed and plant and materials used on such work or at such value therefore as shall，in his opinion，be fair and reasonable．

每月底，承包人應向工程師代表提交一份所使用的勞力、材料和設備（上述規(guī)定的除外）的價目清單，如不按時提供完整的價目清單，承包人將無權得到支付。如工程師有理由認為承包人無法按上述規(guī)定提交清單，他將有權決定把此種工作或作為零工，按工時及使用的材料和設備進行支付，或按他認為公平合理的價格予以支付。

（5）the contractor shall send to the engineer's representative once in every month an account giving particulars，as full and detailed as possible，of all claims for any additional payment to which the contractor may consider himself entitled and of all extra or additional work ordered by the engineer which he has executed during the preceding month，

52．5承包人應每月向工程師代表提交一報告，盡可能全面詳盡地索要他所認為有權要求的一切額外費用，以及陳述上月他按工程師的命令所作的一切額外工作。

no final or interim claim for payment for any such work or expense will be considered which has not been included in such particulars．provided always that the engineer shall be entitled to authorize payment to be made for any such work or expense，notwithstanding the contractor's failure to comply with this condition，if the contractor has，at the earliest practicable opportunity，notified the engineer in writing that he intends to make a claim for such work．

凡未包括在報告中的工作或費用不能在中期或最后給予支付。但如承包人在最初曾書面通知工程師他想就此種工作要求索賠，即使他未遵守上述規(guī)定，工程師也有權要求對此種工作或費用給予支付。

plant，temporary works and materials

設備、臨建工程和材料

53．（1）all constructional plant，temporary works and materials provided by the contractor shall，when brought on to the site，be deemed to be exclusively intended for the execution of the works and the contractor shall not remove the same or any part thereof，except for the purpose of moving it from one part of the site to another，without the consent，in writing，of the engineer，which shall not be unreasonably withheld．

53．1承包人所提供的所有建筑設備、臨建工程設施和材料抵達工地后，應視作完全用于施工，承包人不得移動它們或其任何部分，經(jīng)工程師書面同意，將它們從工地一端移到另一端除外，工程師不得無故不予同意。

（2）upon completion of the works the contractor shall remove from the site all the said constructional plant and temporary works remaining thereon and any unused materials provided by the contractor．

53．2工程完工后，承包人應從工地將所有上述建筑設備、臨建工程設施及按合同所提供的材料的剩余部分清理走。

（3） the employer shall not at any time be liable for the loss of or damage to any of the said constructional plant, temporary works or materials or as mentioned in clauses 20 and 65 hereof．

53．3業(yè)主對上述建筑材料、臨建工程及材料的損失或損壞概不負責，本合同第20和第65條規(guī)定的除外。

（4）in respect of any constructional plant which the contractor shall have imported for the purposes of the works，the employer will assist the contractor，where required，in procuring any necessary government consent to the re-export of such constructional plant by the contractor upon the removal thereof as aforesaid．

53．4如承包人因工程所需而要進口任何建筑設備，業(yè)主必須應承包人要求協(xié)助其從政 府處得到必要的許可，以便按上述規(guī)定清理現(xiàn)場時重新出口此種建筑設備。

（5）the employer will assist the contractor，where required，in obtaining clearance through

the customs of constructional plant，materials and other things required for the works．

53．5業(yè)主應在需要時協(xié)助承包人為工程所需的建筑設備、材料和其他物品結關。

（6）any other conditions affecting constructional plant，temporary works and materials，shall be set out in part 11 in the clause numbered 53 as may be necessary．

53．6其他任何影響建筑設備、臨建工程設施和材料的條件必要時應在第二部分的第53條予以規(guī)定。

54．the operation of clause 53 hereof shall not be deemed to imply any approval by the engineer of the materials or other matters referred to therein nor shall it prevent the rejection of any such materials at any time by the engineer．

54．本合同第53條的執(zhí)行不得視為默示工程師認可該條款所指的材料或其他事項，也不得妨礙工程師在任何時候拒絕使用任何此種材料。

measurement

測定

55．the quantities set out in the bill of quantities are the estimated quantities of the work，but they are not to be taken as the actual and correct quantities of the works to be executed by the contractor in fulfillment of his obligations under the contract．

55．建筑工程清單所列的工程量為估計數(shù)量，不應視為是承包人履行合同義務所完成的實際工程量。

56．the engineer shall，except as otherwise stated，ascertain and determine by measurement the value in terms of the contract of work done in accordance with the contract．he shall，when he requires any part or parts of the works to be measured，give notice to the contractor's authorized agent or representative，who shall forthwith attend or send a qualified agent to assist the engineer or the engineer's representative in making such measurement，and shall furnish all particulars required by either of them．should the contractor not attend，or neglect or omit to send such agent，then the measurement made by the engineer or approved by him shall be taken to be the correct measurement of the work．for the purpose of measuring such permanent work as is to be measured by records and drawings，the engineer's representative shall prepare recordsand drawings month by month of such work and the contractor，as and when called upon to do soin writing，shall，withinz _______ days，attend to examine and agree such records and drawings with the engineer's representative and shall sign the same when so agreed．if the contractor does not so attend to examine and agree such records and drawings，they shall be taken to be correct． if，after examination of such records and drawings，the contractor does not agree the same or does not sign the same as agreed，they shall nevertheless be taken to be correct，unless the contractor days of such examination，lodge with the engineer's representative，for decision by the engineer，notice in writing of the respects in which such records and drawings are claimed by him to be incorrect．

56．如無另行規(guī)定，工程師應通過測定判斷按合同所完成的工程的價值。如他要求對某部分或某些工程進行測定，他應通知承包人的授權代理人或代表，該代理人或代表應立即參加或派一名合格的代理人協(xié)助工程師或工程師代表進行此種測定，并提供工程師或其代表所要求的一切詳細情況。倘若承包人未參加或忽略或忘記派代理人協(xié)助，工程師所作的測定或他認可的測定，應被視為是對工程所作的正確測定。如永久性工程是靠記錄和圖紙進行測定，工程師代表應按月準備記錄和圖紙，如應書面要求，承包人應當在xx天內(nèi)與工程師代表一起檢查并認可此種記錄和圖紙，一經(jīng)認可，承包人應在記錄和圖紙上簽字。如果承包人不參與檢查，記錄和圖紙應被視為正確無誤。如檢查完此種記錄和圖紙后，承包人不予認可或雖認可但不簽字，該記錄和圖紙仍應被視為正確無誤，除非承包人在此種檢查后xx天內(nèi)書面告知工程師代表，他認為記錄和圖紙中哪些不正確，并要求工程師予以裁決。

57．the works shall be measured net，notwithstanding any ganeral or local custom，except where otherwise specifically described or prescribed in the contract．

57．工程測定應采用凈值，不管一般習慣或當?shù)貞T例如何，本合同另有明文規(guī)定的除外。

provisional sums

暫列款

58．（1）“provisional sum' means a sum included in the contract and so designated in the bill of quantities for the execution of work or the supply of goods，materials，or services，or for contingencies，which sum may be used，in whole or in part，or not at all，at the direction and discretion of the engineer．the contract price shall include only such amounts in respect of the work，supply or services to which such provisional sums relate as the engineer shall approve or determine in accordance with this clause．

58．1“暫列款”是指合同中規(guī)定且列在建筑工程清單上的，按工程師的指令及自由處置的一筆用于施工、提供貨物、材料或服務或用于 意外事故 的金額，可全部或部分使用，或根本不用。凡涉及與暫列款有關的工程、供應或服務的款項，只有經(jīng)工程師按本合同規(guī)定同意或決定使用的方能列人合同價格。

（2）in respect of every provisional sum the engineer shall have power to order：

58．2就每一筆備用款，工程師有權命令用于：

（a）work to be executed，including goods，materials or services to be supplied by the contractor．the contract price shall include the value of such work executed or such goods, materials or services supplied determined in accordance with clause 52 hereof．

施工，包括應由承包人提供的貨物、材料或服務。合同價格應包括按合同第52條規(guī)定用于此種施工或提供的貨物、材料或服務的費用。

（b）work to be executed or goods，materials or services to be supplied by a nominated sub-contractor as hereinafter defined．the sum to be paid to the contractor therefor shall be determined and paid in accordance with clause 59（4）hereof．

由下文所規(guī)定的指定轉包人的施工，提供的貨物、材料或服務。由此付給承包人的款項應按本合同第59條第4款的規(guī)定確定并支付。

（c）goods and materials to be purchased by the contractor．the sum to be paid to the contractor therefor shall be determined and paid in accordance with clause 59（4）hereof．

承包人所購買的貨物和材料。由此支付給承包人的款項應按本合同第59條第4款確定并支付。

（3）the contractor shall，when required by the engineer，produce all quotations，invoices，

vouchers and accounts or receipts in connection with expenditure in respect of provisional sums．

58．3凡工程師要求，承包人應提供與暫列款有關的開支的所有報價單、發(fā)票、憑證、賬目或收據(jù)。

nominated sub-contractors

指定分包人

59．（1）all specialists，merchants，tradesmen and others executing any work or supplying any goods，materials or services for which provisional sums are included in the contract，who may have been or be nominated or selected or approved by the employer or the engineer，and all persons to whom by virtue of the provisions of the contract the contractor is required to sub-let any work shall，in the execution of such work or the supply of such goods，materials or services， be deemed to be sub-contractors employed by the contractor and are referred to in this contract

as“nominated sub-contractors”．

59．1所有在合同暫列款項下施工或提供任何貨物、材料或服務的已由或將由業(yè)主或工程師指定或挑選的專家、商人、手工工人和其他人，以及所有根據(jù)合同規(guī)定，得到承包人任何分包工程且由此施工、提供貨物、材料或服務的人，均應被視為是由承包人雇用的轉包人，在本合同中稱為“指定分包人”。

（2）the contractor shall not be required by the employer or the engineer or be deemed to be under any obligation to employ any nominated sub-contractor against whom the contractor may raise reasonable objection，or who shall decline to enter into a sub-contract with the contractor containing provisions：

59．2承包人不得因業(yè)主或工程師的要求，或被認為有任何義務而雇用其有理由反對的，或不與其簽署含有下列規(guī)定的合同的指定分包人：

（a）that in respect of the work，goods，materials or services the subject of the sub-contract，the nominated sub一contractor will undertake towards the contractor the like obligations and liabilities as are imposed on the contractor towards the employer by the terms ofthe contract and will save harmless and indemnify the contractor from and against the same and from all claims，proceedings，damages，costs，charges and expenses whatsoever arising out of or in connection therewith，or arising out of or in connection with any failure to perform such obligations or to fulfil such liabilities，and

就工程、貨物、材料或服務，轉包 合同當事人 ，即指定分包人將對承包人承擔本合同所規(guī)定的承包人應對業(yè)主承擔的同樣的義務和責任，并不讓承包人再履行此義務和責任，且不讓其受因履行此種義務和責任而產(chǎn)生或與之有關的，或因不履行此種義務或責任而產(chǎn)生或與之有關的一切索賠、訴訟、損害賠償金、訴訟費、開支和費用的損害，以及

（b）that the nominated sub-contractor will save harmless and indemnify the contractor from and against any negligence by the nominated sub-contractor，his agents，workmen and servants and from and against any misuse by him or them of any constructional plant or temporary works provided by the contractor for the purposes of the contract and from all claims as aforesaid．

指定分包人應使承包人不因指定分包人、其代理人、工人和雇員的過失而受任何損害，不因分包人、其代理人、工人和雇員不當使用承包人按合同所提供的工程設備或臨建工程而受損害，以及不因上述所有的索賠而受損害。

（3）if in connection with any provisional sum the services to be provided include any matter of design or specification of any part of the permanent works or of any equipment or plant to be incorporated therein，such requirement shall be expressly stated in the contract and shall be included in any nominated sub-contract．the nominated sub-contract shall specify that the nominated sub-contractor providing such services will save harmless and indemnify the contractor from and against the same and from all claims，proceedings，damages，costs，charges and expenses whatsoever arising out of or in connection with any failure to perform such obligations or to fulfil such liabilities．

59．3如暫列款項下所提供的服務包括任何設計事項或對任何一部分永久性工程的詳細規(guī)定，或說明工程所使用的任何設備的規(guī)格，此種要求應在合同中明文規(guī)定，且寫進指定分包合同。指定分包合同應明確規(guī)定，提供此種服務的指定分包人應不讓承包人承擔此種服務，且不讓承包人因未履行此種義務或因履行此種義務而引起的或有關的任何索賠、訴訟、損害賠償金、訴訟費、開支和費用而受損害。

（4）for all work executed or goods，materials，or services supplied by any nominated sub-contractor，there shall be included in the contract price．

59．4就指定分包人所進行的所有施工，提供的貨物、材料或服務而言，應納人合同價格中的有：

（a） the actual price paid or due to be paid by the contractor，on the direction of the engineer，and in accordance with the sub-contract：

按工程師的指令及根據(jù)分包合同，已實際由或應由承包人支付的款項；

（b) the sum，if any，entered in the bill of quantities for labor supplied by the contractor in connection therewith，or if ordered by the engineer pursuant to clause 58（2）（b）hereof，as may be determined in accordance with clause 52 hereof；

涉及建筑工程清單中所列的（如果有）由承包人提供勞務的，或可能由工程師按本合同第58條第2款所命令的，且可根據(jù)本合同第52條確定的款項；

（c）in respect of all other charges and profit，a sum being a percentage rate of the actual price paid or due to be paid calculated，where provision has been made in the bill of quantities for a rate to be set against the relevant provisional sum，at the rate inserted by the contractor against that item or，where no such provision has been made，at the rate inserted by the contractor in the appendix to the tender and repeated where provision for such is made in a special item provided in the bill of quantities for such purpose．

就所有其他費用和收益而言，應采用用一百分比率乘以實際支付或即將支付的款額所得出款項計算，如建筑工程清單已有對有關暫定款列定一個比率的規(guī)定，則應按承包人就該項目列定的比率予以計算，如無此種規(guī)定，則應按承包人在標書附錄所列的，且建筑工程清單已就該具體項目作出認可的比率計算。

（5）before issuing，under clause 60 hereof，any certificate，which includes any payment in respect of work done or goods，materials or services supplied by any nominated sub-contractor， the engineer shall be entitled to demand from the contractor reasonable proof that all payments，less retention，included in previous certificates in respect of the work or goods，materials or services of such nominated sub-contractor have been paid or discharged by the contractor，in default whereof unless the contractor shall：

59．5在按本合同第65條出具任何證書前，若其包括有關任何指定分包人所完成的工程，提供的貨物、材料或服務的任何付款，工程師有權要求承包人提供充足 證據(jù) ，證明包括在先前證書中的有關該指定分包人的工程或貨物、材料或服務的付款，已全部由承包人支付或清償，否則將視為拖欠，除非承包人：

（a) inform the engineer in writing that he has reasonable cause for withholding or refusing to make such payments and

書面通知工程師，他有充足理由不予或拒絕此種付款支付，且

（b）produce to the engineer reasonable proof that he has so informed such nominated sub-contractor in writing，

向工程師提供充足證據(jù)，證明他已就此書面通知該指定分包人，

the employer shall be entitled to pay to such nominated sub-contractor direct，upon the certificate of the engineer，all payments，less retention，provided for in the sub-contract， which the contractor has failed to make to such nominated sub-contractor and to deduct by way of set-off the amount so paid by the employer from any sums due or which may become due from the employer to the contractor．

業(yè)主有權在工程師出具證書后，向該指定分包人直接支付按規(guī)定應由承包人向該指定分包人支付，然而卻沒有支付的所有款項，留置款除外，然后從業(yè)主應支付或即將支付給承包人的任何款項中將此筆付款抵銷。

provided always that，where the engineer has certified and the employer has paid direct as aforesaid，the engineer shall in issuing any further certificate in favor of the contractor deduct from the amount thereof the amount so paid，direct as aforesaid，but shall not withhold or delay the issue of the certificate itself when due to be issued under the terms of the contract．

如工程師已出具證書，且業(yè)主已直接作出上述支付，工程師在向承包人出具任何其他證書，應把業(yè)主直接支付的上述款項扣出，但工程師不得拒絕或延誤出具按本合同規(guī)定應出具的證書本身。

（6）in the event of a nominated sub-contractor，as hereinbefore defined，having undertaken towards the contractor in respect of the work executed，or the goods，materials or services supplied by such nominated sub-contractor，any continuing obligation extending for a period exceeding that of the period of maintenance under the contract，the contractor shall at any time after the expiration period of maintenance，assign to the employer，at the employer's request and cost，the benefit of such obligation for the unexpired duration thereof．

59．6如上所規(guī)定，如果指定分包人在施工，或提供貨物、材料、或服務中對承包人承擔的義務期限超過本合同所規(guī)定的維修期，承包人應在維修期滿后，隨時把此種義務在期滿前所產(chǎn)生的利益應業(yè)主的要求轉讓給業(yè)主，費用由業(yè)主承擔。

certificates and payment

證書和付款

60．（1）unless otherwise provided， payment shall be made at monthly intervals in accordance with the conditions set out in part ii in the clause numbered 60．

60．1除另有規(guī)定外，付款應按第二部分第60條的規(guī)定，分月進行。

（2）where advances are to be made by the employer to the contractor in respect of constructional plant and materials，the conditions of payment and repayment shall be as set out in part ii in the clause numbered 60．

60．2如業(yè)主向承包人預付有關建筑設備和材料的款項，付款和還款的條件應在第二部分第60條中予以規(guī)定。

（3）if the execution of the works shall necessitate the importation of materials，plant or equipment from a country other than that in which the works are being executed，or if the works or any part thereof are to be executed by labor imported from any other such country，or if any other circumstances shall render it necessary or desirable，a proportion of the payments to be made under the contract shall be made in the appropriate foreign currencies and in accordance with the provisions of clause 72 hereof．the conditions under which such payments are to be made shall be as set out in part ii in the clause numbered 60．

60．3如因施工需從施工所在地國的他國進口材料、設備，或因工程或任何部分工程需由此種他國輸入的勞務完成，或因任何其他情況必需或必要，合同項下的某部分付款需按本合同第72條的規(guī)定用有關外匯進行支付，支付條件應按合同第二部分第60條的規(guī)定處理。

61．no certificate other than the maintenance certificate referred to in clause 62 hereof shall be deemed to constitute approval of the works．

61．除本合同第62條所述的維修證書外，任何證書不得視為是對工程的認可。

62．（1）the contract shall not be considered as completed until a maintenance certificate shall have been signed by the engineer and delivered to the employer stating that the works have been completed and maintained to his satisfaction．the maintenance certificate shall be given by the engineer within days after the expiration of the period of maintenance，or，ifdifferent periods of maintenance shall become applicable to different sections or parts of the works，the expiration of the latest such period，or as～thereafter as any works ordered during such period，pursuant to clause 49 and 50 hereof，shall have been completed to the satisfaction of the engineer and full effect shall be given to this clause，notwithstanding any previous entry on the works or the taking possession，working or using thereof or any part thereof by the employer．provided always that the issue of the maintenance certificate shall not be a condition precedent to payment to the contractor of the second portion of the retention money in accordance with the conditions set out in part ii in the clause numbered 60．

62．1只有工程師簽發(fā)了維修證書且交給業(yè)主，說明工程已完工，維修情況令他滿意，才能視合同已經(jīng)完全履行。工程師應在維修期滿后，或，如工程的不同部分適用不同的維修期，在最后一個維修期滿后xx天內(nèi)簽發(fā)維修證書，或在所有在此維修期中，按本合同第49和第50條規(guī)定，命令進行的工程完成且令工程師滿意后立即簽發(fā)，本條款必須全面執(zhí)行，不管先前業(yè)主是否已進人、占有或使用工程或工程的任何部分。維修證書的簽發(fā)不得作為按第二部分第60條的規(guī)定向承包人支付第二筆留置款的前提條件。

（2）the employer shall not be liable to the contractor for any matter or thing arising out of or in connection with the contract or the execution of the works，unless the contractor shall have made a claim in writing in respect thereof before the giving of the maintenance certificate under this clause．

62．2業(yè)主不得因本合同或施工所產(chǎn)生或與之有關的任何事項對承包人負責，除非承包人在簽發(fā)本條款規(guī)定的維修證書前，就此種事項已提出書面索賠。

（3）notwithstanding the issue of the maintenance certificate the contractor and，subject to subclause（2）of this clause，the employer shall remain liable for the fulfillment of any obligation incurred under the provisions of the contract prior to the issue of the maintenance certificate which remains unperformed at the time such certificate is issued and，for the purposes of determining the nature and extent of any such obligation，the contract shall be deemed to remain in force between the parties hereto．

62．3盡管簽發(fā)了維修證書，承包人以及業(yè)主（但應符合本條第2款的規(guī)定）仍應對發(fā)生在證書簽發(fā)前而在證書簽發(fā)時尚未履行的合同義務負責，為決定此種義務的性質及范疇，應本合同繼續(xù)對合同雙方有效。

remedies and powers

補救和權力

63．（1）if the contractor shall become bankrupt，or have a receiving order made against him，or shall present his petition in bankruptcy，or shall make an arrangement with or assignment in favor of his creditors，or shall agree to carry out the contract under a committee of inspection of his creditors or，being a corporation，shall go into liquidation（other than a voluntary liquidation for the purposes of amalgamation or reconstruction），or if the contractor shall assign the contract，without the consent in writing of the employer first obtained，or shall have an execution levied on his goods，or if the engineer shall certify in writing to the employer that inhis opinion the contractor：

63．1如果承包人破產(chǎn)，或被法院下達破產(chǎn)者產(chǎn)業(yè)管理接收令，或遞交破產(chǎn)申請，或與 債權人 簽訂清償協(xié)議或進行 債權轉讓 ，或同意在債權人決議委任的破產(chǎn)監(jiān)督委員會監(jiān)督下執(zhí)行本合同，或，如其是一個公司，將被 清算 （不是因合并或重組而進行的自愿清算），或承包人事先未征得業(yè)主的書面同意而 轉讓合同 ，或其貨物被扣押，或工程師書面向業(yè)主證明，他認為承包人：

（a） has abandoned the contract，or

已經(jīng)撤銷合同，或

（b）without reasonable excuse has failed to commence the works or has suspended the progress of the works for__ days after receiving from the engineer written notice to proceed，or

沒有正當理由但卻不開工，或在收到工程師要求繼續(xù)工程的書面通知后，停工_______天，或

（c）has failed to remove materials from the site or to pull down and replace work for

days after receiving from the engineer written notice that the said materials or work had been condemned and rejected by the engineer under these conditions，or

在收到工程師書面通知，說明某些材料不適用或某工程應予否決后_______天內(nèi)未從工地搬走這些材料，或未拆毀此種工程重建，或

（d）despite previous warnings by the engineer，in writing，is not executing the works in accordance with the contract，or is persistently or flagrantly neglecting to carry out his obligations under the contract，or

不按合同施工，或長期或公然不履行其合同義務，盡管工程師已書面提出 警告 ，或

（e) has，to the detriment of good workmanship，or in defiance of the engineer's instructions to the contrary，sub-let any part of the contract，

不顧工作質量，或無視工程師的指示，轉包任何合同部分，

then the employer may，after giving _______days’notice in writing to the contractor，enter upon the site and the works and expel the contractor therefrom without thereby voiding the contract，or releasing the contractor from any of his obligations or liabilities under the contract or affecting the rights and powers conferred on the employer or the engineer by the contract， and may himself complete the works or may employ any other contractor to complete the works． the employer or such other contractor may use for such completion so much of the constructional plant，temporary works and materials，which have been deemed to be reserved exclusively for the execution of the works，under the provisions of the contract，as he or they may think proper，and the employer may，at any time，sell any of the said constructional plant，temporary works and unused materials and apply the proceeds of sale in or towards the satisfaction of any sums due or which may become due to him from the contractor under the contract．

此時，業(yè)主可在書面通知承包人_______天后進駐工地，并將承包人逐出，由此不會造成 合同無效 ，或解除承包人的任何合同義務或責任，或影響合同賦予業(yè)主或工程師的權利和權力，業(yè)主可自己完成工程或另雇其他承包人完成工程。為完成工程，業(yè)主和其他承包人可充分使用其認為合適的，按本合同規(guī)定被視為是專門為施工而保留的建筑設備、臨建工程和材料，業(yè)主可隨時出售上述任何建筑設備、臨建工程和未使用的材料，并將出售收人抵付按合同規(guī)定承包人應支付或可能支付給他的任何款項。

（2）the engineer shall，as soon as may be practicable after any such entry and expulsion by the employer，fix and determine ex parte，or by or after reference to the parties，or after such investigation or inquiries as he may think fit to make or institute，and shall certify what amount， if any，had at the time of such entry and expulsion been reasonably earned by or would reasonably accrue to the contractor in respect of work then actually done by him under the contract and the value of any of the said unused or partially used materials，any constructional plant and any temporary works．

63．2業(yè)主進駐工地并逐走承包人之后，工程師應盡快單方面，或通過了解雙方當事人，或在作過他所認為恰當?shù)恼{查或咨詢之后作出安排或決定，并證明到此種進駐與被逐時為止，按事實上已完成的合同工程，承包人已獲得或理應獲得的款項（如果有），以及計算出上述任何未使用或只部分使用的材料、建筑設備和臨建工程的價值。

（3）if the employer shall enter and expel the contractor under this clause，he shall not be liable to pay to the contractor any money on account of the contract until the expiration of the period of maintenance and thereafter until the costs of execution and maintenance，damages for delay in completion， if any，and all other expenses incurred by the employer have been ascertained and the amount thereof certified by the engineer．the contractor shall then be entitled to receive only such sum or sums，if any，as the engineer may certify would have been payable to him upon due completion by him after deducting the said amount．if such amount shall exceed the sum which would have been payable to the contractor on due completion by him，then the contractor shall，upon demand，pay to the employer the amount of such excess and it shall be deemed a debt due by the contractor to the employer and shall be recoverable accordingly．

63．3如果業(yè)主按本條規(guī)定進駐工地并逐走承包人，他應在維修期滿，且所有施工和維修費、延誤完工賠償費（如果有）、和業(yè)主所發(fā)生的其他費用被核實，且經(jīng)工程師證明后，方才負責對承包人按合同進行支付。此時，承包人有權得到的款額（如果有）僅為工程師證明，因他妥善完工而應得的款額減去上述款項之差。如上述費用超過承包人妥善完工應得的款額，經(jīng)要求，承包人得向業(yè)主支付此超出部分款額，超出部分應視為承包人對業(yè)主的負債，且可照此收回。

64．if，by reason of any accident，or failure，or other event occurring to in or in connection with the works，or any part thereof，either during the execution of the works，or during the period of maintenance，any remedial or other work or repair shall，in the opinion of the engineer or the engineer's representative，be urgently necessary for the safety of the works and the contractor is unable or unwilling at once to do such work or repair，the employer may employ and pay other persons to carry out such work or repair as the engineer or the engineer's representative may consider necessary．if the work or repair so done by the employer is work which，in the opinion of the engineer，the contractor was liable to do at his own expense under the contract，all expenses properly incurred by the employer in so doing shall be recoverable from the contractor by the employer，or may be deducted by the employer from any monies due or which may become due to the contractor．provided always that the engineer or the engineer's representative，as the case may be，shall，as soon after the occurrence of any such emergency as may be reasonably practicable，notify the contractor thereof in writing．

64．如在施工或維修期間，因工程或部分工程發(fā)生或涉及任何意外、或事故、或其他事件，工程師或工程師代表認為需馬上進行補救或其他工作或修理，以保證工程的安全，而承包人無法或不愿馬上進行此種工作或修理，業(yè)主可雇用并支付他人進行工程師或工程師代表認為必要的此種工作或修理。如工程師認為，業(yè)主所進行的此種工作屬于承包人按合同規(guī)定應自己付費完成的工作，業(yè)主由此所發(fā)生的一切費用應由業(yè)主向承包人收回，或從其應付給或可能應付給承包人的款項中扣除。在此種任何緊急事件發(fā)生后，工程師或工程師代表應根據(jù)情況，盡快書面告知承包人。

special risks

特定風險

65．notwithstanding anything in the contract contained：

65．本合同任何條款均服從以下規(guī)定：

（1）the contractor shall be under no liability whatsoever whether by way of indemnity or otherwise for or in respect of destruction of or damage to the works，save to work condemned under the provisions of clause 39 hereof prior to the occurrence of any special risk hereinafter mentioned，or to property whether of the employer or third parties，or for or in respect of injury or loss of life which is the consequence of any special risk as hereinafter defined．the employer shall indemnify and save harmless the contractor against and from the same and against and from all claims，proceedings，damages，costs，charges and expenses whatsoever arising thereout or in connection therewith．

65．1任何責任，不論屬于賠償或其他，也不論其是有關或涉及工程（以下提及的任何特定風險發(fā)生前，已按本合同第39條宣布為不適用的工程除外）、業(yè)主或第三當事人的財產(chǎn)的毀壞或損壞，或有關或涉及人員傷亡，只要是因以下所規(guī)定的特定風險導致，承包人慨不負責。業(yè)主必須保證承包人不受上述情況以及由此所引起的任何索賠、訴訟、損害賠償金、訴訟費、開支和費用的損害。

（2）if the works or any materials on or near in transit to the site，or any other property of the

contractor used or intended to be used for the purposes of the works，shall sustain destruction or damage by reason of any of the said special risks the contractor shall be entitled to payment for：

65．2如工程或任何在工地、或從附近運往工地的材料，或承包人其他用于或旨在用于工地的任何財產(chǎn)因上述特定風險受到毀壞或損壞，承包人有權得到以下償付：

（a）any permanent work and for any materials so destroyed or damaged，

因此而被毀壞或損壞的任何永久性工程或材料，

and，so far as may be required by the engineer，or as may be necessary for the completion of the works，on the basis of cost plus such profit as the engineer may certify to be reasonable；

以及，只要工程師要求，或工程完工所必需，按成本費加上工程師證明合理的利潤為基準支付；

（b）replacing or making good any such destruction or damage to the works；

恢復或補償工程被如此毀壞或損壞的部分；

（c）replacing or making good such materials or other property of the contractor used． intended to be used for the purposes of the works．

恢復或補償承包人用于或旨在于工程的此種材料或其他財產(chǎn)。

（3）destruction，damage，injury or loss of life caused by the explosion or impact whenever and wherever occurring of any mine，bomb，shell，grenade，or other projectile，missile， munitions，or explosive of war，shall be deemed to be a consequence of the said special risks．

65．3因地雷、炸彈、炮彈、手榴彈、或其他射彈、導彈、彈藥、或軍用炸藥的爆炸或沖擊（不論時間和地點）所導致的毀壞、損害、受傷或死亡應被視為是上述特定風險的結果。

（4）the employer shall repay to the contractor any increased cost of or incidental to the execution of the works，other than such as may be attributable to the cost of reconstructing work condemned under the provisions of clause 39 hereof，prior to the occurrence of any special risk， which is howsoever attributable to or consequent on or the result of or in any way whatsoever connected with the said special risks，subject however to the provisions in this clause hereinafter contained in regard to outbreak of war，but the contractor shall as soon as any such increase of cost shall come to his knowledge forthwith notify the engineer thereof in writing．

65．4除本條以下關于戰(zhàn)爭爆發(fā)的規(guī)定外，業(yè)主應償還承包人因上述特定風險而發(fā)生的 任何施工額外或附加費用，在任何特定風險發(fā)生前按合同第39條視為不適用的工程的重建費不在此列，承包人一旦知道此種費用增加，必須立即書面通知工程師。

（5）the special risks are war，hostilities（whether war be declared or not），invasion，act of foreign enemies，the nuclear and pressure-waves risk described in clause 20（2）hereof，or insofar as it relates to the country in which the works are being or are to be executed or maintained，rebellion，revolution，insurrection，military or usurped power，civil war，or，unless solely restricted to the employees of the contractor or of his sub-contractors and arising from the conduct of the works，riot，commotion or disorder．

65．5特定風險指戰(zhàn)爭、戰(zhàn)爭狀態(tài)（不論宣戰(zhàn)予否）、侵略、外國敵對行為、本合同第20條第2款規(guī)定的核危險和聲波風險、或與正在或即將施工或維修的工程所在地國有關的反叛、革命、暴動、軍事政變、篡權、內(nèi)戰(zhàn)，或（只是由承包人或其轉包人的雇員和因施工引起的除外）騷亂、動亂或混亂。

（6）if，during the currency of the contract，there shall be an outbreak of war，whether war is declared or not，in any part of the world which，whether financially or otherwise，materially affects the execution of the works，the contractor shall，unless and until the contract is terminated under the provisions of this clause，continue to use his best endeavors to complete the execution of the works．provided always that the employer shall be entitled at any time after such outbreak of war to terminate the contract by giving written notice to the contractor and， upon such notice being given，this contract shall，except as to the rights of the parties under this clause and to the operation of clause 67 hereof，terminate，but without prejudice to the rights of either party in respect of any antecedent breach thereof．

65．6在合同執(zhí)行時，如世界任何地方爆發(fā)戰(zhàn)爭，無論宣戰(zhàn)與否，是否在財政或其他方面對工程造成了重大影響，除非和在本合同按本條款規(guī)定終止前，承包人應繼續(xù)盡力完成工程。業(yè)主在戰(zhàn)爭爆發(fā)后隨時有權書面通知承包人終止合同，一旦此種通知發(fā)出，除本條所規(guī)定的雙方權利和第67條的規(guī)定外，合同應當終止，但不得損害任何一方與以前任何違約有關的一切權利。

（7）if the contract shall be terminated under the provisions of the last preceding sub-clause， the contractor shall，with all reasonable dispatch，remove from the site all constructional plant

and shall give similar facilities to his sub-contractors to do so．

65．7如合同按上一款規(guī)定終止，承包人應迅速從工地移走所有建筑設備，并向其轉包人提供同樣的轉移設施。

（8）if the contract shall be terminated as aforesaid，the contractor shall be paid by the employer，insofar as such amounts or items shall not have already been covered by payments on account made to the contractor，for all work executed prior to the date of termination at the rates and prices provided in the contract and in addition．

65．8如果合同如上終止，就承包人所得的暫付款項中尚未包括的在終止之日前已完成工作的款項，業(yè)主應按本合同所規(guī)定的價格支付給承包人，此外還應支付：

（a） the amounts payable in respect of any preliminary items，、far as the work or service

comprised therein has been carried out or performed，and a proper proportion as certified by the engineer of any such items，the work or service comprised in which has been partially carried out or performed．

所有有關臨時單據(jù)應予支付的款項，只要單據(jù)所含的工作或服務已經(jīng)完成，如此種單據(jù)所含的工作或服務只完成一部分，則只支付經(jīng)工程師確認的應予支付的那一部分款項。

（b） the cost of materials or goods reasonably ordered for the works which shall have been delivered to the contractor or of which the contractor is legally liable to accept delivery，such materials or goods becoming the property of the employer upon such payments being made by him．

因工程而訂購的材料或貨物的合理費用，包括已運交承包人的和承包人按法律有義務接收的材料或貨物，業(yè)主向承包人付款后，這些材料或貨物即成為業(yè)主的財產(chǎn)。

（c）a sum to be certified by the engineer，being the amount of any expenditure reasonably incurred by the contractor in the expectation of completing the whole of the works insofar as such expenditure shall not have been covered by the payments in this sub-clause before mentioned．

經(jīng)工程師確認的，承包人為完成整個工程而發(fā)生的合理費用，只要本款上述各種費用未將此費用包括在內(nèi)。

（d）any additional sum payable under the provisions of sub-clauses（1），（2）and（4）of this clause．

本條第1、第2和第4款所規(guī)定的追加付款。

（e）the reasonable cost of removal of constructional plant under sub-clause（7）of this clause and，if required by the contractor，return thereof the contractor's main plant yard in his country of registration or to other destination，at no greater cost．

本條第7款所規(guī)定的搬遷建筑設備的合理費用，如果承包人要求，包括將此設備運回到承包人注冊國的主要設備堆置場的費用，或運至其他地點的費用，但此費用不得超過運回注冊國的費用。

（f） the reasonable cost of repatriation of all the contractor's staff and workmen employed on or in connection with the works at the time of such termination．

合同終止 時，遣返承包人雇用在工程上或與之有關的職員和工人的合理費用。

provided always that against any payments due from the employer under this sub-clause the employer shall be entitled to be credited with any outstanding balances due from the contractor for advances in respect of constructional plant and materials and any other sums which at the date of termination wear recoverable by the employer from the contractor under the terms of the contract．

對本款項下業(yè)主應予支付的款項，業(yè)主有權用承包人的應付款來抵沖，包括建筑設備及材料的預付款的未償余額，以及其他任何在合同終止日按合同條款業(yè)主有權向承包人回收的款項。

frustration

受挫失效

66．if a war，or other circumstances outside the control of both parties，arises after the contract is made so that either party is prevented from fulfilling his contractual obligations，or under the law governing the contract，the parties are released from further performance，then the sum payable by the employer to the contractor in respect of the work executed shall be the same as that which would have been payable under clause 65 hereof if the contract had been terminated under the provisions of clause 65 hereof．

66．如合同締結后爆發(fā)戰(zhàn)爭，或出現(xiàn)雙方無法控制的其他情況，使得任何一方無法履行其合同義務，或根據(jù)合同適用的法律，雙方被解除了繼續(xù)履約的義務，由業(yè)主對已完成的工程而支付承包人的款額應當?shù)扔诎幢竞贤?5條規(guī)定之金額，即如果合同根據(jù)第65條之規(guī)定終止時，應當支付的金額。

settlement of disputes

爭議的解決

67．if any dispute or difference of any kind whatsoever shall arise between the employer and the contractor or the engineer and the contractor in connection with，or arising out of the contract，or the execution of the works，whether during the progress of the works or after their completion and whether before or after the termination，abandonment or breach of the contract， it shall，in the first place，be referred to and settled by the engineer who shall，within a period of

_______days after being requested by either party to do so，give written notice of his decision to the employer and the contractor．subject to arbitration，as hereinafter provided，such decision in respect of every matter so referred shall be final and binding upon the employer and the contractor and shall forthwith be given effect to by the employer and by the contractor，who shall proceed with the execution of the works with all due diligence whether he or the employer requires arbitration, as hereinafter provided，or not．if the engineer has given written notice of his decision to the employer and the contractor and no claim to arbitration has been communicated to him by either the employer or the contractor within a period of _______days from receipt of such notice，the said decision shall remain final and binding upon the employer and the contractor． if the engineer shall fail to give notice of his decision，as aforesaid，within a period of _______ days

after being requested as aforesaid，or if either the employer or the contractor be dissatisfied withany such decision，then and in any such case either the employer or the contractor may within _______ days after receiving notice of such decision，or within _______days after the expiration of the first-named period of _______days，as the case may be，require that the matter or matters in dispute be referred to arbitration as hereinafter provided．a(chǎn)ll disputes or differences in respect of which the decision，if any，of the engineer has not become final and binding as aforesaid shall be finally settled under the rules of conciliation and arbitration of the international chamber of commerce by one or more arbitrators appointed under such rules．the said arbitrator/s shall have full power to open up，revise and review any decision，opinion， direction, certificate or valuation of the engineer．neither party shall be limited in the proceedings before such arbitrator/s to the evidence or arguments put before the engineer for the purpose of obtaining his said decision．no decision given by the engineer in accordance with the foregoing provisions shall disqualify him from being called as a witness and giving evidence before the arbitrator/s on any matter whatsoever relevant to the dispute or difference referred to the arbitrator/s as aforesaid．the reference to arbitration may proceed notwithstanding that the works shall not then be or be alleged to be complete，provided always that the obligations of the employer，the engineer and the contractor shall not be altered by reason of the arbitration being

conducted during the progress of the works．

67．業(yè)主與承包人或工程師與承包人因合同或工程施工而發(fā)生的或與之有關的任何爭議或分歧，無論是在施工中還是在完工后，無論是在合同終止、撤銷或違約前后，首先應當提交工程師解決，應任何一方要求后_______天內(nèi)，工程師必須將其決定書面通知業(yè)主和承包人。除按以下規(guī)定提出仲裁外，此種有關上述所有事項的決定為最終決定，對業(yè)主和承包人均有約束力的，且立即對業(yè)主和承包人生效，承包人應繼續(xù)施工并盡一切應有的注意，無論他或業(yè)主或承包人是否要按以下規(guī)定提請仲裁。在工程師將決定書面通知業(yè)主和承包人后，如_______天內(nèi)未收到業(yè)主或承包人的仲裁申請，上述決定應作為最終決定，對業(yè)主和承包人均有約束力。如工程師未按上述規(guī)定應要求在_______天內(nèi)通知其決定，或業(yè)主或承包人對此種決定不滿意，在此后或此種情況下，業(yè)主或承包人可在收到?jīng)Q定通知_______天內(nèi)，或在最先所說的_______天期滿后_______天內(nèi)，視情況而定，將爭議事項按下述規(guī)定提交仲裁。所有爭議或分歧，凡工程師的有關決定（如果有）如上所述不再是最終和有約束力的，均應由根據(jù)《國際商會調解和仲裁規(guī)則》所指定的一名或多名仲裁員按該規(guī)則規(guī)定予以最終解決。上述仲裁員（們）有權評論、修正和復審工程師的任何決定、意見、指示、證書或估價。在仲裁過程中，任何一方均可不受限制地向仲裁員（們）提供當時供工程師作出決定而采用的證據(jù)或論據(jù)。不論工程師按上述規(guī)定曾作過何種決定，均不得剝奪其被 傳喚 作為 證人 ，且就按上述規(guī)定提交仲裁的爭議或分歧的任何有關事項向仲裁員（們）提供證據(jù)的資格。不論工程尚未或認為尚未完工，均可提請仲裁，但業(yè)主、工程師和承包人的義務不得因在施工進程中提起仲裁而改變。

notice

通知

68．（1）all certificates，notices or written orders to be given by the employer or by the engineer to the contractor under the terms of the contract shall be served by sending by post toor delivering the same to the contractor's principal place of business，or such other address as the contractor shall nominate for this purpose．

68．1業(yè)主或工程師按合同條款給予承包人的所有證書、通知或書面命令均應郵寄或送 交至承包人的主要營業(yè)地，或承包人指定的其他通訊地址。

（2）all notices to be given to the employer or to the engineer under the terms of the contract shall be served by sending by post or delivering the same to the respective addresses nominated for that purpose in part 11 of these conditions．

68．2所有按本合同條款給予業(yè)主或工程師的通知均應郵寄或送交至第二部分有關通知條款所指定的其各自的地址。

（3）either party may change a nominate address to another address in the country where the works are being executed by prior written notice to the other party and the engineer may do so by prior written notice to both parties．

68．3任何一方均可把一指定地址改為在施工地國的另外一個地址，但事先應書面通知另一方，工程師在改變地址前需書面通知雙方當事人。

default of employer

業(yè)主違約

69．（1）in the event of the employer：

69．1如果業(yè)主：

（a）failing to pay to the contractor the amount due under any certificate of the engineer within_______days after the same shall have become due under the terms of the contract，subject to any deduction that the employer is entitled to make under the contract，or

在工程師證書所認定的應付款項按合同條款到期_______天內(nèi)未向承包人支付，業(yè)主按合同有權所作的扣除部分除外，或

（b）interfering with or obstructing or refusing any required approval to the issue of any such

certificate，or

干涉或阻礙或拒絕同意頒發(fā)任何此種證書，或

（c）becoming bankrupt or，being a company，going into liquidation，other than for the purpose of a scheme of reconstruction or amalgamation，or

破產(chǎn)或、如為公司，即將被清算，而此種清算不是為了重組或合并，或

（d）giving formal notice to the contractor that for unforeseen reasons，due to economic dislocation，it is impossible for him to continue to meet his contractual obligations．

正式通知承包人，因不可預見的原因，鑒于經(jīng)濟混亂，其無法再履行其合同義務，

the contractor shall be entitled to terminate his employment under the contract after

givingday's prior written notice to the employer，with a copy to the engineer．

承包人應有權在提前xx天書面通知業(yè)主，并將副本呈交工程師后，終止其合同雇傭關系。

（2）upon the expiry of the _______ days’notice referred to in sub-clause（1）of this clause，

the contractor shall，notwithstanding the provisions of clause 53（1）hereof，with all reasonable

dispatch，remove from the site all constructional plant brought by him thereon．

69．2本條第1款規(guī)定的_______天通知期限到期后，盡管本合同第53條第1款作有規(guī)定，承包人仍然應盡量迅速地從工地撤走他所帶來的所有建筑設備。

（3）in the event of such termination the employer shall be under the same obligations to the contractor in regard to payment as if the contract had been terminated under the provisions of clause 65 hereof，but，in addition to the payments specified in clause 65（8）hereof，the employer shall pay to the contractor the amount of any loss or damage to the contractor arising out of or in connection with or by consequence of such termination．

69．3如果合同如此終止，業(yè)主必須向承包人承擔本合同按第65條規(guī)定終止時一樣的支付義務，但除了第65條第8款所規(guī)定的款項外，業(yè)主還必須向承包人支付因合同由此終止而造成的或有關的或導致的滅失或損失費。

changes in costs and legislation

費用與法規(guī)的變更

70．（1）adjustments to the contract price shall be made in respect of rise or fall in the costs of labor and/or materials or any other matters affecting the cost of the execution of the works，as

set out in part ii in the clause numbered 70．

70．1合同價格的調整應與勞工或／和材料成本的增減，或其他任何影響施工費用的事項相關，應按第二部分第70條規(guī)定執(zhí)行。

（2）if，of ter the date _______days prior to the latest date for submission of tenders for the works there occur in the country in which the works are being or are to be executed changes to any national or state statute，ordinance，decree or other law or any regulation or by一law of any local or other duly constituted authority，or the introduction of any such state statute， ordinance，decree，law，regulation or by-law which causes additional or reduced cost to the contractor，other than under sub-clause（1）of this clause，in the execution of the works such additional or reduced cost shall be certified by the engineer and shall be paid by or credited to the employer and the contract price adjusted accordingly．

70．2在提交工程標書最后期限前的_________天之后，如施工或即將施工工程所在地國的任何國家或州的法規(guī)、法令、政令或其他任何地方和其他權力機構的法律或條例或規(guī)章發(fā)生變化，或適用了使承包人的施工費用發(fā)生增減（非本條第1款所述的增減）的任何州的法規(guī)法令、政令、法律、條例或規(guī)章，此種費用增減應經(jīng)工程師證明，且由業(yè)主支付或記人貸方，合同價格也應作相應調整。

currency and rates of exchange

貨幣和匯率

71．if，after the date________days prior to the latest date for submission of tenders for the

works the government or authorized agency of the government of the country in which the works are being or are to be executed imposes currency restrictions and/or transfer of currency restrictions in relation to the currency or currencies in which the contract price is to be paid theemployer shall reimburse any loss or damage to the contractor arising therefrom，without prejudice to the right of the contractor to exercise any other rights or remedies to which he is entitled in such event．

71．在提交標書最后期限前的xx天之后，如施工或即將施工工程所在地國的政府或政府授權機構對合同價格計價貨幣實行貨幣 管制 和／或貨幣兌換管制，業(yè)主應補償由此對承包人造成的一切損失或損害，承包人在此種情況下有權行使其他任何權利或補救措施不得由此而受影響。

72．（1）where the contract provides for payment in whole or in part to be made to the contractor in foreign currency or currencies，such payment shall not be subject to variations in the rate or rates of exchange between such specified foreign currency or currencies and the currency of the country in which the works are to be executed．

72．1如果合同規(guī)定，承包人的支付應全部或部分使用一種或多種外幣，此種支付不得受特定外幣與施工工程所在地國的貨幣間的匯率變化的影響。

（2）where the employer shall have required the tender to be expressed in a single currency but with payment to be made in more than one currency and the contractor has stated the proportions or amounts of other currency or currencies in which he requires payment to be made the rate or rates of exchange applicable for calculating the payment of such proportions or amounts shall be those prevailing，as determined by the central bank of the country in which the works are to be executed，on the date days prior to the latest date for the submission of tenders for the works，as shall have been notified to the contractor by the employer prior to the submission of tenders or as provided for in the tender documents．

72．2如業(yè)主要求標書計價只用一種貨幣，而支付卻用多種貨幣，且承包人已說明他要求用其他貨幣支付的比例或數(shù)額，用于計算此種比例或數(shù)額支付的貨幣兌換率應為現(xiàn)行匯率，即由施工所在地國的中央銀行在提交標書最后期限前的xx天當日所決定的匯率，就此，業(yè)主必須在標書提交前告知承包人，或在投標文件中予以寫明。

（3）where the contract provides for payment in more than one currency，the proportions or amounts to be paid in foreign currencies in respect of provisional sum items shall be determined in accordance with the principles set forth in sub-clause（1）and（2）of this clause as and when these sums are utilized in whole or in part in accordance with the provisions of clause 58 and 59 hereof．

72．3如合同規(guī)定使用多種貨幣支付，凡涉及按本合同第58和第59條規(guī)定使用暫列款的項目，其用外匯支付的比例或數(shù)額應按本條第1和第2款制定的原則予以確定。

for part i clauses is included hereinafter．

（本部分以下所列規(guī)定是對第一部分條款在各種具體情況下的補充或修改。）

（以下略）

第4篇 國際土木工程招投標新

國際工程承包是一種較復雜的國際經(jīng)濟技術合作方式，因工程資金金額較大、技術性較強、對工期質量亦有較高要求，所以工程的發(fā)包人一般均采用國際競爭性招投標來選擇合適的承包人，以保證中標者是在經(jīng)濟上和技術上有實力的公司。被選中的投標人即與發(fā)包人（業(yè)主）簽訂合同，并按合同最后規(guī)定的價格、質量、工期等條件履行合同。

國際工程招投標主要包含以下幾個步驟：

＊刊登資格預審廣告

＊資格預審（土建工程項目一般都要進行資格預審）

＊發(fā)行招標文件

＊投標

＊開標評標

＊授予合同

＊簽訂合同

資格預審文件的主要內(nèi)容：

資格預審通知

資格預審申請人須知

資格預審申請人填寫的調查表

表1資格預審申請書

表2一般情況表

表3財務數(shù)據(jù)表

表4工作經(jīng)驗記錄表

表5擬用于本工程的設備

表6擬派往本工程的人員表

表7現(xiàn)場組織計劃

a.初步現(xiàn)場組織框圖

b.初步現(xiàn)場組織框圖文字詳述

c.總部和現(xiàn)場管理部門之間的關系

分包人

聯(lián)營體資料

招標文件的主要內(nèi)容

在對申請資格預審的投標者所提交的資格預審書進行審查后，業(yè)主即向已通過資格預審的招標者發(fā)出招標邀請及招標文件，其主要內(nèi)容如下：

＊邀標書

＊投標者需知

＊投標表格及附件

＊合同條款

a.合同的一般條款

b.合同的特殊條款

＊合同協(xié)議書的格式

＊工程的范圍

＊工程量清單

＊工程進度表

＊圖紙

＊投標及履約保函

2.1邀標書（范例）

邀標書

日期：（發(fā)出邀請時間）___________

貸款編號：_______________________

合同編號：_______________________

1.（借方名稱）已經(jīng)從亞洲開發(fā)*行（adb）收到一筆用于支付（工程名稱）費用的以各種貨幣形式體現(xiàn)的貸款，該貸款收入的一部分將用于支付_______工程合同項目下的合格費用。

2.（業(yè)主名稱）現(xiàn)從亞-行成員國中邀請有預選資格的合格投標者進行密封投標，為實施及完成工程提供所需要的勞務、材料、設備及服務。

3.投標者可從標書上獲得進一步的信息，可從（______）辦公室查閱投標文件和資料。（買方單位名稱），（發(fā)放投標資料及資料辦公室的郵政地址、電傳電報號）。

4.有興趣的合格投標者可向上述地址提出書面申請并交付一筆不可退用的金額，即可購買一整套投標文件資料。

5.所有的投標者都需繳納總投標價的2％或一定金額的保證金，并按投標需知于開標前交清，然后立即公開開標。

6.（業(yè)主）不負擔投標人因準備或提交投標所發(fā)生的任何開支或費用，包括與參觀現(xiàn)場有關的開支或費用。

7.不考慮可選擇標

（可提交與規(guī)范說明中的規(guī)范不一致但卻滿足要求的或達到規(guī)范的可選擇標。

但只有主標為最低評估標時，可選擇標才會被考慮?？蛇x擇標需與主標分開，密封并標明“可選擇標”。）

貸款號：_______________

合同號：_______________

2.2投標書

投標書

致：____________（業(yè)主名稱）

敬啟者：

研究了上述合同的投標文件，包括圖紙、合格條件、技術規(guī)范和工程量清單，我簽署方愿意以投標書和附錄（附錄號）中所規(guī)定的要求，以_________金額（大寫數(shù)字和阿拉伯數(shù)字）或合同可能規(guī)定的其他金額，承擔上述工程的施工、建成和維護工作。

如對方接受我方投標，我方保證在______天內(nèi)開工，并在合同規(guī)定的時間完工并交付工程。該日期從開工日算起并與本合同第7條所規(guī)定的工程進度表要求一致。

如果我方中標，我們將按合同價格的百分之十出具履約保函，以保證合同的正常執(zhí)行。

我方同意從“投標者須知”第24條所規(guī)定的標書截止日起的______天內(nèi)遵守本投標。此標在該期限結束前始終對我們有約束力，并可隨時被接受。

在正式合同制定和簽署前，本投標書連同您方的書面中標通知書應視為約束我們雙方的合同。

我們理解您方有權不接受最低標價的投標，或者其他任何你們可能收到的投標。

__________年_______月_______日

（簽字）

以________的資格正式授權并代表

（投標人的名稱與地址）

（證人簽字）

證人姓名：____________________

地址：________________________

第5篇 國際土木工程招投標合同

貸款編號：＿＿＿＿

合同編號：＿＿＿＿

1.（借方名稱）已經(jīng)從亞洲開發(fā)銀行（adb）收到一筆用于支付（工程名稱）費用的以各種貨幣形式體現(xiàn)的貸款，該貸款收入的一部分將用于支付××工程合同項目下的合格費用。

2.（業(yè)主名稱）現(xiàn)從亞行成員國中邀請有預選資格的合格投標者進行密封投標，為實施及完成工程提供所需要的勞務、材料、設備及服務。

3.投標者可從標書上獲得進一步的信息，可從（××）辦公室查閱投標文件和資料。（買方單位名稱），（發(fā)放投標資料及資料辦公室的郵政地址、電傳電報號）。

4.有興趣的合格投標者可向上述地址提出書面申請并交付一筆不可退用的金額，即可購買一整套投標文件資料。

5.所有的投標者都需繳納總投標價的2％或一定金額的保證金，并按投標需知于開標前交清，然后立即公開開標。

6.（業(yè)主）不負擔投標人因準備或提交投標所發(fā)生的任何開支或費用，包括與參觀現(xiàn)場有關的開支或費用。

7.不考慮可選擇標

（可提交與規(guī)范說明中的規(guī)范不一致但卻滿足要求的或達到規(guī)范的可選擇標。

但只有主標為最低評估標時，可選擇標才會被考慮?？蛇x擇標需與主標分開，密封并標明“可選擇標”。）

貸款號：＿＿

合同號：＿＿

2.2投標書

投標書

致：＿＿＿＿（業(yè)主名稱）

敬啟者：

研究了上述合同的投標文件，包括圖紙、合格條件、技術規(guī)范和工程量清單，我簽署方愿意以投標書和附錄（附錄號）中所規(guī)定的要求，以×××金額（大寫數(shù)字和阿拉伯數(shù)字）或合同可能規(guī)定的其他金額，承擔上述工程的施工、建成和維護工作。

如對方接受我方投標，我方保證在××天內(nèi)開工，并在合同規(guī)定的時間完工并交付工程。該日期從開工日算起并與本合同第7條所規(guī)定的工程進度表要求一致。

如果我方中標，我們將按合同價格的百分之十出具履約保函，以保證合同的正常執(zhí)行。

我方同意從“投標者須知”第24條所規(guī)定的標書截止日起的＿＿天內(nèi)遵守本投標。此標在該期限結束前始終對我們有約束力，并可隨時被接受。

在正式合同制定和簽署前，本投標書連同您方的書面中標通知書應視為約束我們雙方的合同。

我們理解您方有權不接受最低標價的投標，或者其他任何你們可能收到的投標。

19＿＿年×月×日

（簽字）

以＿＿的資格正式授權并代表

（投標人的名稱與地址）

（證人簽字）

證人姓名：＿＿＿＿＿

地址：＿＿＿＿

第6篇 招標合同:國際土木工程招投標

日期：_________年_________月_________日（發(fā)出邀請時間）

貸款編號：_________

合同編號：_________

1．_________（借方名稱）已經(jīng)從_________銀行收到一筆用于支付_________（工程名稱）費用的以各種貨幣形式體現(xiàn)的貸款，該貸款收入的一部分將用于支付_________工程合同項目下的合格費用。

2．_________（業(yè)主名稱）現(xiàn)從_________成員國中邀請有預選資格的合格投標者進行密封投標，為實施及完成工程提供所需要的勞務、材料、設備及服務。

3．投標者可從標書上獲得進一步的信息，可從（_________）辦公室查閱投標文件和資料。_________（買方單位名稱、發(fā)放投標資料及資料辦公室的郵政地址、電傳電報號）。

4．有興趣的合格投標者可向上述地址提出書面申請并交付一筆不可退用的金額，即可購買一整套投標文件資料。

5．所有的投標者都需繳納總投標價的2％或一定金額的保證金，并按投標需知于開標前交清，然后立即公開開標。

6．_________（業(yè)主）不負擔投標人因準備或提交投標所發(fā)生的任何開支或費用，包括與參觀現(xiàn)場有關的開支或費用。

7．不考慮可選擇標（可提交與規(guī)范說明中的規(guī)范不一致但卻滿足要求的或達到規(guī)范的可選擇標。但只有主標為最低評估標時，可選擇標才會被考慮。可選擇標需與主標分開，密封并標明“可選擇標”。）

第7篇 國際土木工程招投標文本

* 資格預審（土建工程項目一般都要進行資格預審）

* 發(fā)行 招標 文件

* 投標

* 開標評標

* 授予合同

* 簽訂合同

資格預審文件的主要內(nèi)容：

資格預審通知

資格預審申請人須知

資格預審申請人填寫的調查表

表1 資格預審申請書

表2 一般情況表

表3 財務數(shù)據(jù)表

表4 工作經(jīng)驗記錄表

表5 擬用于本工程的設備

表6 擬派往本工程的人員表

表7 現(xiàn)場組織計劃

a.初步現(xiàn)場組織框圖

b.初步現(xiàn)場組織框圖文字詳述

c.總部和現(xiàn)場管理部門之間的關系

分包人

聯(lián)營體資料

招標文件的主要內(nèi)容

在對申請資格預審的投標者所提交的資格預審書進行審查后，業(yè)主即向已通過資格預審的招標者發(fā)出招標邀請及招標文件，其主要內(nèi)容如下：

* 邀標書

* 投標者需知

* 投標表格及附件

* 合同條款

a.合同的一般條款

b.合同的特殊條款

* 合同協(xié)議書的格式

* 工程的范圍

* 工程量清單

* 工程進度表

* 圖紙

* 投標及履約保函

2.1 邀標書（范例）

邀標書

日期：（發(fā)出邀請時間）

貸款編號：____

合同編號：____

1.（借方名稱）已經(jīng)從亞洲開發(fā)*行（adb ）收到一筆用于支付（工程名稱）費用的以各種貨幣形式體現(xiàn)的貸款，該貸款收入的一部分將用于支付×× 工程合同 項目下的合格費用。

2.（業(yè)主名稱）現(xiàn)從亞-行成員國中邀請有預選資格的合格投標者進行密封投標，為實施及完成工程提供所需要的勞務、材料、設備及服務。

3.投標者可從標書上獲得進一步的信息，可從（××）辦公室查閱投標文件和資料。（買方單位名稱），（發(fā)放投標資料及資料辦公室的郵政地址、電傳電報號）。

4.有興趣的合格投標者可向上述地址提出書面申請并交付一筆不可退用的金額，即可購買一整套投標文件資料。

5.所有的投標者都需繳納總投標價的2%或一 定金 額的 保證金 ，并按投標需知于開標前交清，然后立即公開開標。

6.（業(yè)主）不負擔投標人因準備或提交投標所發(fā)生的任何開支或費用，包括與參觀現(xiàn)場有關的開支或費用。

7.不考慮可選擇標

（可提交與規(guī)范說明中的規(guī)范不一致但卻滿足要求的或達到規(guī)范的可選擇標。

但只有主標為最低評估標時，可選擇標才會被考慮?？蛇x擇標需與主標分開，密封并標明“可選擇標”。）

貸款號：__

合同號：__

2.2 投標書

投標書

致：____（業(yè)主名稱）

敬啟者：

研究了上述合同的投標文件，包括圖紙、合格條件、技術規(guī)范和工程量清單，我簽署方愿意以投標書和附錄（附錄號）中所規(guī)定的要求，以×××金額（大寫數(shù)字和阿拉伯數(shù)字）或合同可能規(guī)定的其他金額，承擔上述工程的施工、建成和維護工作。

如對方接受我方投標，我方保證在××天內(nèi)開工，并在合同規(guī)定的時間完工并交付工程。該日期從開工日算起并與本合同第7 條所規(guī)定的工程進度表要求一致。

如果我方中標，我們將按合同價格的百分之十出具履約保函，以 保證合同 的正常執(zhí)行。

我方同意從“投標者須知”第24條所規(guī)定的標書截止日起的__天內(nèi)遵守本投標。此標在該期限結束前始終對我們有約束力，并可隨時被接受。

在正式合同制定和簽署前，本投標書連同您方的書面中標通知書應視為約束我們雙方的合同。

我們理解您方有權不接受最低標價的投標，或者其他任何你們可能收到的投標。

20__年×月×日

（簽字）

以__的資格正式授權并代表

（投標人的名稱與地址）

（ 證人 簽字）

證人姓名：_____

地址：____

第8篇 招標合同：國際土木工程招投標

這篇《招標合同范文：國際土木工程招投標（邀請書）》是小編為大家整理的，希望對大家有所幫助。以下信息僅供參考?。?！

日期：_________年_________月_________日（發(fā)出邀請時間）

貸款編號：_________

合同編號：_________

1._________（借方名稱）已經(jīng)從_________銀行收到一筆用于支付_________（工程名稱）費用的以各種貨幣形式體現(xiàn)的貸款，該貸款收入的一部分將用于支付_________工程合同項目下的合格費用。

2._________（業(yè)主名稱）現(xiàn)從_________成員國中邀請有預選資格的合格投標者進行密封投標，為實施及完成工程提供所需要的勞務、材料、設備及服務。

3.投標者可從標書上獲得進一步的信息，可從（_________）辦公室查閱投標文件和資料。_________（買方單位名稱、發(fā)放投標資料及資料辦公室的郵政地址、電傳電報號）。

4.有興趣的合格投標者可向上述地址提出書面申請并交付一筆不可退用的金額，即可購買一整套投標文件資料。

5.所有的投標者都需繳納總投標價的2％或一定金額的保證金，并按投標需知于開標前交清，然后立即公開開標。

6._________（業(yè)主）不負擔投標人因準備或提交投標所發(fā)生的任何開支或費用，包括與參觀現(xiàn)場有關的開支或費用。

7.不考慮可選擇標（可提交與規(guī)范說明中的規(guī)范不一致但卻滿足要求的或達到規(guī)范的可選擇標。但只有主標為最低評估標時，可選擇標才會被考慮?？蛇x擇標需與主標分開，密封并標明“可選擇標”。）

第9篇 國際土木工程招投標

國際工程承包是一種較復雜的國際經(jīng)濟技術合作方式，因工程資金金額較大、

技術性較強、對工期質量亦有較高要求，所以工程的發(fā)包人一般均采用國際競爭性

招投標來選擇合適的承包人，以保證中標者是在經(jīng)濟上和技術上有實力的公司。被

選中的投標人即與發(fā)包人（業(yè)主）簽訂合同，并按合同最后規(guī)定的價格、質量、工

期等條件履行合同。

國際工程招投標主要包含以下幾個步驟：

＊ 刊登資格預審廣告

＊ 資格預審（土建工程項目一般都要進行資格預審）

＊ 發(fā)行招標文件

＊ 投標

＊ 開標評標

＊ 授予合同

＊ 簽訂合同

資格預審文件的主要內(nèi)容：

資格預審通知

資格預審申請人須知

資格預審申請人填寫的調查表

表１ 資格預審申請書

表２ 一般情況表

表３ 財務數(shù)據(jù)表

表４ 工作經(jīng)驗記錄表

表５ 擬用于本工程的設備

表６ 擬派往本工程的人員表

表７ 現(xiàn)場組織計劃

ａ．初步現(xiàn)場組織框圖

ｂ．初步現(xiàn)場組織框圖文字詳述

ｃ．總部和現(xiàn)場管理部門之間的關系

分包人

聯(lián)營體資料

招標文件的主要內(nèi)容

在對申請資格預審的投標者所提交的資格預審書進行審查后，業(yè)主即向已通過

資格預審的招標者發(fā)出招標邀請及招標文件，其主要內(nèi)容如下：

＊ 邀標書

＊ 投標者需知

＊ 投標表格及附件

＊ 合同條款

ａ．合同的一般條款

ｂ．合同的特殊條款

＊ 合同協(xié)議書的格式

＊ 工程的范圍

＊ 工程量清單

＊ 工程進度表

＊ 圖紙

＊ 投標及履約保函

２．１ 邀標書（范例）

邀標書

日期：（發(fā)出邀請時間）

貸款編號：＿＿＿＿

合同編號：＿＿＿＿

１．（借方名稱）已經(jīng)從亞洲開發(fā)*行（ａｄｂ）收到一筆用于支付（工程名

稱）費用的以各種貨幣形式體現(xiàn)的貸款，該貸款收入的一部分將用于支付××工程

合同項目下的合格費用。

２．（業(yè)主名稱）現(xiàn)從亞-行成員國中邀請有預選資格的合格投標者進行密封投

標，為實施及完成工程提供所需要的勞務、材料、設備及服務。

３．投標者可從標書上獲得進一步的信息，可從（××）辦公室查閱投標文件

和資料。（買方單位名稱），（發(fā)放投標資料及資料辦公室的郵政地址、電傳電報

號）。

４．有興趣的合格投標者可向上述地址提出書面申請并交付一筆不可退用的金

額，即可購買一整套投標文件資料。

５．所有的投標者都需繳納總投標價的２％或一定金額的保證金，并按投標需

知于開標前交清，然后立即公開開標。

６．（業(yè)主）不負擔投標人因準備或提交投標所發(fā)生的任何開支或費用，包括

與參觀現(xiàn)場有關的開支或費用。

７．不考慮可選擇標

（可提交與規(guī)范說明中的規(guī)范不一致但卻滿足要求的或達到規(guī)范的可選擇標。

但只有主標為最低評估標時，可選擇標才會被考慮。可選擇標需與主標分開，密封

并標明“可選擇標”。）

貸款號：＿＿

合同號：＿＿

２．２ 投標書

投標書

致：＿＿＿＿（業(yè)主名稱）

敬啟者：

研究了上述合同的投標文件，包括圖紙、合格條件、技術規(guī)范和工程量清單，

我簽署方愿意以投標書和附錄（附錄號）中所規(guī)定的要求，以×××金額（大寫數(shù)

字和阿拉伯數(shù)字）或合同可能規(guī)定的其他金額，承擔上述工程的施工、建成和維護

工作。

如對方接受我方投標，我方保證在××天內(nèi)開工，并在合同規(guī)定的時間完工并

交付工程。該日期從開工日算起并與本合同第７條所規(guī)定的工程進度表要求一致。

如果我方中標，我們將按合同價格的百分之十出具履約保函，以保證合同的正

常執(zhí)行。

我方同意從“投標者須知”第２４條所規(guī)定的標書截止日起的＿＿天內(nèi)遵守本

投標。此標在該期限結束前始終對我們有約束力，并可隨時被接受。

在正式合同制定和簽署前，本投標書連同您方的書面中標通知書應視為約束我

們雙方的合同。

我們理解您方有權不接受最低標價的投標，或者其他任何你們可能收到的投標。

１９＿＿年×月×日

（簽字）

以＿＿的資格正式授權并代表

（投標人的名稱與地址）

（證人簽字）

證人姓名：＿＿＿＿＿

地址：＿＿＿＿

第10篇 國際土木工程招投標（投標書）新整理版

合同號：_________

貸款號：_________

致：_________（業(yè)主名稱）

研究了上述合同的 投標 文件，包括圖紙、合格條件、技術規(guī)范和工程量清單，我簽署方愿意以投標書和附錄（附錄號）中所規(guī)定的要求，以_________金額（大寫數(shù)字和阿拉伯數(shù)字）或合同可能規(guī)定的其他金額，承擔上述工程的施工、建成和維護工作。

如對方接受我方投標，我方保證在_________天內(nèi)開工，并在合同規(guī)定的時間完工并交付工程。該日期從開工日算起并與本合同第7條所規(guī)定的工程進度表要求一致。

如果我方中標，我們將按合同價格的_________出具履約保函，以 保證合同 的正常執(zhí)行。

我方同意從“投標者須知”第24條所規(guī)定的標書截止日起的_________天內(nèi)遵守本投標。此標在該期限結束前始終對我們有約束力，并可隨時被接受。

在正式合同制定和簽署前，本投標書連同您方的書面中標通知書應視為約束我們雙方的合同。

我們理解您方有權不接受最低標價的投標，或者其他任何你們可能收到的投標。

投標人（簽字）：_________

證人 （簽字）：_________

_________年____月____日

第11篇 國際土木工程招投標邀請書

日期：________年____月____日(發(fā)出邀請時間)貸款編號：_________合同編號：_________

1._________(借方名稱)已經(jīng)從_________銀行收到一筆用于支付_________(工程名稱)費用的以各種貨幣形式體現(xiàn)的貸款，該貸款收入的一部分將用于支付_________工程合同項目下的合格費用。

2._________(業(yè)主名稱)現(xiàn)從_________成員國中邀請有預選資格的合格投標者進行密封投標，為實施及完成工程提供所需要的勞務、材料、設備及服務。

3.投標者可從標書上獲得進一步的信息，可從(_________)辦公室查閱投標文件和資料。_________(買方單位名稱、發(fā)放投標資料及資料辦公室的xx地址、電傳電報號)。

4.有興趣的合格投標者可向上述地址提出書面申請并交付一筆不可退用的金額，即可購買一整套投標文件資料。

5.所有的投標者都需繳納總投標價的2%或一定金額的保證金，并按投標需知于開標前交清，然后立即公開開標。

6._________(業(yè)主)不負擔投標人因準備或提交投標所發(fā)生的任何開支或費用，包括與參觀現(xiàn)場有關的開支或費用。

7.不考慮可選擇標(可提交與規(guī)范說明中的規(guī)范不一致但卻滿足要求的或達到規(guī)范的可選擇標。但只有主標為最低評估標時，可選擇標才會被考慮?？蛇x擇標需與主標分開，密封并標明可選擇標。)

第12篇 國際土木工程招投標（投標書）

合同號：_________

貸款號：_________

致：_________（業(yè)主名稱）

研究了上述合同的投標文件，包括圖紙、合格條件、技術規(guī)范和工程量清單，我簽署方愿意以投標書和附錄（附錄號）中所規(guī)定的要求，以_________金額（大寫數(shù)字和阿拉伯數(shù)字）或合同可能規(guī)定的其他金額，承擔上述工程的施工、建成和維護工作。

如對方接受我方投標，我方保證在_________天內(nèi)開工，并在合同規(guī)定的時間完工并交付工程。該日期從開工日算起并與本合同第7條所規(guī)定的工程進度表要求一致。

如果我方中標，我們將按合同價格的_________出具履約保函，以保證合同的正常執(zhí)行。

我方同意從“投標者須知”第24條所規(guī)定的標書截止日起的_________天內(nèi)遵守本投標。此標在該期限結束前始終對我們有約束力，并可隨時被接受。

在正式合同制定和簽署前，本投標書連同您方的書面中標通知書應視為約束我們雙方的合同。

我們理解您方有權不接受最低標價的投標，或者其他任何你們可能收到的投標。

投標人（簽字）：_________

證人（簽字）：_________

_________年____月____日

第13篇 招標合同 ：國際土木工程招投標

招標合同范文 ：國際土木工程招投標

國際工程承包是一種較復雜的國際經(jīng)濟技術合作方式，因工程資金金額較大、技術性較強、對工期質量亦有較高要求，所以工程的發(fā)包人一般均采用國際競爭性招投標來選擇合適的承包人，以保證中標者是在經(jīng)濟上和技術上有實力的公司。被選中的投標人即與發(fā)包人（業(yè)主）簽訂合同，并按合同最后規(guī)定的價格、質量、工期等條件履行合同。

國際工程招投標主要包含以下幾個步驟：

＊刊登資格預審廣告

＊資格預審（土建工程項目一般都要進行資格預審）

＊發(fā)行招標文件

＊投標

＊開標評標

＊授予合同

＊簽訂合同

資格預審文件的主要內(nèi)容：

資格預審通知

資格預審申請人須知

資格預審申請人填寫的調查表

表1資格預審申請書

表2一般情況表

表3財務數(shù)據(jù)表

表4工作經(jīng)驗記錄表

表5擬用于本工程的設備

表6擬派往本工程的人員表

表7現(xiàn)場組織計劃

a.初步現(xiàn)場組織框圖

b.初步現(xiàn)場組織框圖文字詳述

c.總部和現(xiàn)場管理部門之間的關系

分包人

聯(lián)營體資料

招標文件的主要內(nèi)容

在對申請資格預審的投標者所提交的資格預審書進行審查后，業(yè)主即向已通過資格預審的招標者發(fā)出招標邀請及招標文件，其主要內(nèi)容如下：

＊邀標書

＊投標者需知

＊投標表格及附件

＊合同條款

a.合同的一般條款

b.合同的特殊條款

＊合同協(xié)議書的格式

＊工程的范圍

＊工程量清單

＊工程進度表

＊圖紙

＊投標及履約保函

2.1邀標書（范例）

邀標書

日期：（發(fā)出邀請時間）

貸款編號：＿＿＿＿

合同編號：＿＿＿＿

1.（借方名稱）已經(jīng)從亞洲開發(fā)銀行（adb）收到一筆用于支付（工程名稱）費用的以各種貨幣形式體現(xiàn)的貸款，該貸款收入的一部分將用于支付××工程合同項目下的合格費用。

2.（業(yè)主名稱）現(xiàn)從亞行成員國中邀請有預選資格的合格投標者進行密封投標，為實施及完成工程提供所需要的勞務、材料、設備及服務。

3.投標者可從標書上獲得進一步的信息，可從（××）辦公室查閱投標文件和資料。（買方單位名稱），（發(fā)放投標資料及資料辦公室的郵政地址、電傳電報號）。

4.有興趣的合格投標者可向上述地址提出書面申請并交付一筆不可退用的金額，即可購買一整套投標文件資料。

5.所有的投標者都需繳納總投標價的2％或一定金額的保證金，并按投標需知于開標前交清，然后立即公開開標。

6.（業(yè)主）不負擔投標人因準備或提交投標所發(fā)生的任何開支或費用，包括與參觀現(xiàn)場有關的開支或費用。

7.不考慮可選擇標

（可提交與規(guī)范說明中的規(guī)范不一致但卻滿足要求的或達到規(guī)范的可選擇標。

但只有主標為最低評估標時，可選擇標才會被考慮?？蛇x擇標需與主標分開，密封并標明“可選擇標”。）

貸款號：＿＿

合同號：＿＿

2.2投標書

投標書

致：＿＿＿＿（業(yè)主名稱）

敬啟者：

研究了上述合同的投標文件，包括圖紙、合格條件、技術規(guī)范和工程量清單，我簽署方愿意以投標書和附錄（附錄號）中所規(guī)定的要求，以×××金額（大寫數(shù)字和阿拉伯數(shù)字）或合同可能規(guī)定的其他金額，承擔上述工程的施工、建成和維護工作。

如對方接受我方投標，我方保證在××天內(nèi)開工，并在合同規(guī)定的時間完工并交付工程。該日期從開工日算起并與本合同第7條所規(guī)定的工程進度表要求一致。

如果我方中標，我們將按合同價格的百分之十出具履約保函，以保證合同的正常執(zhí)行。

我方同意從“投標者須知”第24條所規(guī)定的標書截止日起的＿＿天內(nèi)遵守本投標。此標在該期限結束前始終對我們有約束力，并可隨時被接受。

在正式合同制定和簽署前，本投標書連同您方的書面中標通知書應視為約束我們雙方的合同。

我們理解您方有權不接受最低標價的投標，或者其他任何你們可能收到的投標。

19＿＿年×月×日

（簽字）

以＿＿的資格正式授權并代表

（投標人的名稱與地址）

（證人簽字）

證人姓名：＿＿＿＿＿

地址：＿＿＿＿

第14篇 招標合同：國際土木工程招投標（邀請書）

日期：_________年_________月_________日（發(fā)出邀請時間）

貸款編號：_________

合同編號：_________

1._________（借方名稱）已經(jīng)從_________銀行收到一筆用于支付_________（工程名稱）費用的以各種貨幣形式體現(xiàn)的貸款，該貸款收入的一部分將用于支付_________工程合同項目下的合格費用。

2._________（業(yè)主名稱）現(xiàn)從_________成員國中邀請有預選資格的合格投標者進行密封投標，為實施及完成工程提供所需要的勞務、材料、設備及服務。

3.投標者可從標書上獲得進一步的信息，可從（_________）辦公室查閱投標文件和資料。_________（買方單位名稱、發(fā)放投標資料及資料辦公室的郵政地址、電傳電報號）。

4.有興趣的合格投標者可向上述地址提出書面申請并交付一筆不可退用的金額，即可購買一整套投標文件資料。

5.所有的投標者都需繳納總投標價的2％或一定金額的保證金，并按投標需知于開標前交清，然后立即公開開標。

6._________（業(yè)主）不負擔投標人因準備或提交投標所發(fā)生的任何開支或費用，包括與參觀現(xiàn)場有關的開支或費用。

7.不考慮可選擇標（可提交與規(guī)范說明中的規(guī)范不一致但卻滿足要求的或達到規(guī)范的可選擇標。但只有主標為最低評估標時，可選擇標才會被考慮。可選擇標需與主標分開，密封并標明“可選擇標”。）